Legal Notices, February 26, 2016

PUBLIC NOTICE INVITING BIDS NOTICE IS HEREBY GIVEN that the CITY OF ENCINITAS invites sealed bids for: LEO MULLEN SPORTS PARK TURF REPLACEMENT PROJECT CP16B Sealed bids will be received at the office of the City Clerk, City Hall, City of Encinitas, 505 S. Vulcan Avenue, Encinitas, CA 92024, until 2:00 p.m., March 17, 2016 at which time they will be publicly opened by the City Clerk and read aloud, for performing the work as follows: LEO MULLEN SPORTS PARK TURF REPLACEMENT PROJECT On the outside of the envelope shall be stated: “Leo Mullen Sports Park Sealed Bid: DO NOT OPEN UNTIL May 17, 2016 at 2:00 P.M.” WORK TO BE DONE: The work to be done generally includes: removal of the existing natural turf, underlying soil, and irrigation system; establishment of new subgrade and installation of synthetic turf with supplemental pad, in-fill material, permeable aggregate base, subsurface drainage system, wash water system, and future lighting infrastructure. Engineer’s Estimate – $1,000,000 (Base Bid only). This project includes potential additive alternates. Potential bidders shall review the plans and complete Specifications carefully and understand the work contained in the Base Bid and each potential alternate before submitting a bid. COMPLETION OF WORK: The Contractor shall diligently prosecute the work to completion within fifty (50) working days from the commencement date contained in the Notice to Proceed. LOWEST RESPONSIVE AND RESPONSIBLE BIDDER: All bids are to be compared on the basis of the City Engineer’s estimate of the quantities of work to be done and the unit prices bid by the bidder. The award of the contract, if it is awarded, will be to the responsive and responsible bidder submitting a Bid whose summation of the base bid and the seven additive alternative bids is the lowest. Pursuant to Public Contract Code Section 1103, a “Responsible Bidder”, means a bidder who has demonstrated the attributes of trustworthiness, as well as quality, fitness, capacity, and experience to satisfactorily perform this public works contract. FIFTY PERCENT “OWN FORCES” REQUIREMENT: Any bid that proposes performance of more than 50 percent of the work by subcontractors or owner operator/lessors or otherwise to be performed by forces other than the Bidder’s own organization will be rejected as non-responsive. OBTAINING CONTRACT DOCUMENTS: Contract documents may be obtained after Monday, February 29, 2016 at the Engineering counter in City Hall located at 505 S. Vulcan Ave., Encinitas, CA 92024, at a non-refundable cost of $30.00 per set. In compliance with California Contract Code, Section 20103.7 electronic copies will be made available to contractor plan series bid boards and contractors upon their request. The project specifications can be electronically downloaded on the City’s ftp site. Please contact Kipp Hefner at (760)633-2775 or khefner@encinitasca.gov to get instructions on how to access the City’s ftp site and to download the project specifications electronically. The City makes no representation regarding the accuracy of Contract Documents received from third party plan rooms and Contractor accepts bid documents from third parties at its own risk. It is highly recommended that contractors interested in the project either pick up project specifications directly from the Encinitas Engineering Counter at City Hall or to download them electronically from the City’s ftp site. Should contractors choose to pick up project specifications at Plan Rooms, the contractors shall still be responsible for obtaining all addendums for the project and signing and submitting all addendums with their bid. Any contractor that does not acknowledge receipt of all addendums by signing and submitting all addendums with their bid shall be deemed a non-responsive bidder and their bid will be rejected. BID INFORMATION: Bids will be submitted in sealed envelopes upon the blank forms furnished by the City. No bid will be considered unless it is made on a proposal form furnished by the City. The work shall be in strict conformity with the Contract documents. In order to bid this project, the Contractor must have at the time of bid award a valid Class A General Engineering Contractor or a valid Class D-12 Synthetic Products Contractor State of California Contractor’s License in good standing and must maintain said license in good standing throughout the course of the project, and the contractor must be registered with the California Department of Industrial Relations. Certain specialty licenses may be required of certain work as set forth in the specifications. The Contractor is responsible to insure that all proper licenses are maintained. No bid will be awarded to a Contractor who is not licensed in accordance with the provisions of chapter 9, Division 3 of the Business and Professions Code or is not registered with the California Department of Industrial Relations. Withdrawal of bids by Contractor shall not be permitted for a period of ninety (90) days after the date set for the opening thereof. BID SECURITY: Each bid must be accompanied by cash, certified or cashier’s check, or bidder’s bond made payable to the City of Encinitas for an amount equal to at least ten percent (10%) of the amount bid, such guarantee to be forfeited should the bidder to whom the contract is awarded fail to enter into the contract. Additional information on bid security requirements can be found in the project Specifications included with the Bid Package. All bonds shall be issued by an admitted carrier qualified to do business in California. PRE-BID QUESTIONS AND MANDATORY PRE-BID CONFERENCE: A mandatory pre- Bid Conference will be conducted at 10:00 AM, March 7, 2016 at the project site, 951 Via Cantebria, Encinitas, CA. Any interested bidders must attend; Contractors who intend to bid on this project must sign in and be in attendance of the entire meeting in order to be eligible to bid. The pre-bid meeting is informational only. The bidder shall not rely upon any representations made at the meeting or site visit in preparing its bid, but shall rather rely solely upon the written Contract Documents and any contract addenda issued prior to bid opening. Any questions and/or answers that may affect the bid will be included in an addendum to the bid documents and sent to all the planholders. The City will answer information requests on this project up to Noon on Monday, March 14, 2016. After Noon on Monday, March 14, 2016 no more questions or information requests will be answered and only plan holders list will be either e-mailed or faxed to interested parties during that time. All questions regarding the Contract Documents shall be submitted by e-mail only and must be directed to Kipp Hefner khefner@encinitasca.gov. All City substantive responses will be provided to all properly registered plan holders by addenda or other written means of communication. LIQUIDATED DAMAGES: The Contractor shall pay to the City of Encinitas the sum of Two-Thousand Dollars ($2,000.00) per day for each and every calendar day of unexcused total project delay in completing the work in excess of the number of working days prescribed above. EQUALS: Notwithstanding if the project plans or specifications designate specific brands, materials, items or trade names, the Bidder may submit proposed equals to the Contract, pursuant to Public Contract Code Section 3400. Any contractor seeking a request for a substitution of “an equal” item shall submit all necessary data substantiating a request at least five business days prior to the bid opening date. RIGHT TO REJECT ALL BIDS: The City reserves the right to reject all bids at its sole discretion and to waive any immaterial irregularities or informalities in the bids received. PREVAILING WAGE: This is a prevailing wage project and prevailing wage rates for this locality and project as determined by the Director of Industrial Relations apply, pursuant to labor code section 1770, et. Seq. A copy of the prevailing wage rates shall be posted on the job site by the contractor. A schedule of prevailing wage rates is available for review at the California Department of Industrial Relations web site found on the internet at http://www.dir.ca.gov/Public-Works/Prevailing-Wage.html. The successful bidder shall be required to pay at least the wage rates set forth in that schedule. Certified Payroll records shall be maintained by the contractor and copies of the certified payroll shall be electronically sent to the Department of Industrial Relations and be delivered to the City at the end of each month during the entire duration of the project. Notice: Subject to exceptions as set forth in Labor Code section 1771.1, contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined by statute, unless it is currently registered and qualified to perform public work pursuant to Labor Code Section 1725.5. The City may not accept a bid nor any contract or subcontract entered into without proof of the contractor or subcontractor’s current registration to perform public work pursuant to Section 1725.5. For more information, go to http://www.dir.ca.gov/Public-Works/Certified-Payroll-Reporting.html COMPLIANCE WITH LABOR LAWS: The prime contractor shall be responsible for ensuring compliance with all applicable provisions of the Labor Code, including, but not limited to, section 1777.5. SUBLETTING AND SUBCONTRACTING FAIR PRACTICES ACT: Contractor shall comply with sections 4100 et. seq. of the Public Contracts Code (“Subletting and Subcontracting Fair Practices Act) in all respects. The City is the “duly authorized officer” for the purposes of sections 4107 and 4107.5. PERFORMANCE AND PAYMENT BONDS: Each bid shall be accompanied by security in a form and amount as required by law. The successful bidder will be required to furnish a Payment Bond for one hundred percent (100%), and a Performance Bond for one hundred percent (100%) of the contract amount prior to execution of the contract. The City requires the awarded contractor obtain Payment and Performance bonds, issued by an admitted carrier, qualified to do business in California, as required by Code of Civil Procedure Section 995.120. Pursuant to Public Contract Code section 22300, the City permits the substitution of securities for any moneys withheld to ensure performance under the contract, or, alternatively, the contractor may request and the City may make payment of retentions earned directly to the escrow agent at the expense of the Contractor. NONDISCRIMINATION: During the performance of this contract, the contractor and its subcontractors shall not deny the contract’s benefits to any person on the basis of on race or color; religion; national origin or ancestry, physical disability; mental disability or medical condition; marital status; sex or sexual orientation; age, with respect to persons over the age of 40; and pregnancy, childbirth, or related medical conditions; nor shall they discriminate unlawfully against any employee or applicant for employment because of on race or color; religion; national origin or ancestry, physical disability; mental disability or medical condition; marital status; sex or sexual orientation; age, with respect to persons over the age of 40; and pregnancy, childbirth, or related medical conditions. Contractor shall insure that the evaluation and treatment of employees and applicants for employment are free of such discrimination. PROJECT ADMINISTRATION: All questions relative to this project prior to the opening of bids, including instructions on how to access the City’s ftp site to download the specifications electronically, shall be directed to the City Representative stated below. The bidder shall not rely upon any representations made by City representatives in preparing its bid, but shall rather rely solely upon the written Contract Documents and any contract addenda issued prior to bid opening. City of Encinitas 505 South Vulcan Avenue Encinitas, CA 92024 Telephone: (760) 633-2775 E-mail: khefner@encinitasca.gov Attention: Kipp Hefner Associate Civil Engineer Please also see INFORMATION AND INSTRUCTIONS FOR BIDDERS in bid documents for additional bid information and requirements. City of Encinitas BY: Glenn Pruim, PE February 26, 2015 Director of Public Works END OF NOTICE INVITING BIDS 02/26/16, 03/04/16, 03/11/16 CN 18315

City of Encinitas Planning and Building Department NOTICE OF PENDING ACTION ON ADMINISTRATIVE APPLICATION AND COASTAL DEVELOPMENT PERMIT The Planning & Building Department of the City of Encinitas is currently reviewing the following Administrative Application request. The application submittal is available for your review and comments during regular business hours, 7:00 AM to 6:00 PM Monday through Friday. City Hall is closed alternate Fridays (2/26, 3/11, etc.) CASE NUMBER: 15-198 PMW/CDP FILING DATE: July 28, 2015 APPLICANT: Pisciotta LOCATION: 827 and 829 Hygeia Avenue PROJECT DESCRIPTION: A Parcel Map Waiver and Coastal Development Permit to convert the existing legal nonconforming duplex into a condominium form of ownership. The subject property is located in the Residential 3 (R-8) Zone and the Coastal Zone. ENVIRONMENTAL STATUS: The project has been determined to be exempt from environmental review pursuant to the California Environmental Quality Act (CEQA). PRIOR TO 6:00 PM ON MONDAY, MARCH 7, 2016, ANY INTERESTED PERSON MAY REVIEW THE APPLICATION AND PRESENT TESTIMONY, ORALLY OR IN WRITING, TO THE PLANNING & BUILDING DEPARTMENT. WRITTEN TESTIMONY IS PREFERRED IN ORDER TO HAVE A RECORD OF THE COMMENTS RECEIVED. If additional information is not required, the Planning & Building Department will render a determination on the application, pursuant to Section 2.28.090 of the City of Encinitas Municipal Code, after the close of the review period. An Appeal of the Department’s determination accompanied by the appropriate filing fee may be filed within 10-calendar days from the date of the determination. Appeals will be considered by the City Council pursuant to Chapter 1.12 of the Municipal Code. Any filing of an appeal will suspend this action as well as any processing of permits in reliance thereon in accordance with Encinitas Municipal Code Section 1.12.020(D)(1) until such time as an action is taken on the appeal. The above item is located within the Coastal Zone and requires the issuance of a regular Coastal Development Permit. The action of the Planning & Building Director may not be appealed to the California Coastal Commission. Under California Government Code Sec. 65009, if you challenge the nature of the proposed action in court, you may be limited to raising only those issues you or someone else raised regarding the matter described in this notice or written correspondence delivered to the City at or prior to the date and time of the determination. For further information, contact J. Dichoso at 760-633-2681, or by e-mail at jdichoso@encinitasca.gov; or the Planning & Building Department at 760-633-2710, or by e-mail at planning@encinitasca.gov, 505 S. Vulcan Avenue, Encinitas, CA 92024. 02/26/16 CN 18311

NOTICE OF PUBLIC HEARING AND AVAILABILITY OF PUBLIC REVIEW HOUSING AUTHORITY OF THE CITY OF ENCINITAS Proposed Amendments to Section 8 Housing Choice Voucher Program Administrative Plan PLACE OF MEETING: Council Chambers, Civic Center 505 South Vulcan Avenue Encinitas, CA 92024 THE CITY OF ENCINITAS IS AN EQUAL OPPORTUNITY PUBLIC ENTITY AND DOES NOT DISCRIMINATE ON THE BASIS OF RACE, COLOR, NATIONAL ORIGIN, SEX, RELIGION, AGE OR DISABILITY IN EMPLOYMENT OR THE PROVISION OF SERVICE. IN COMPLIANCE WITH THE AMERICANS WITH DISABILITIES ACT/SECTION 504 REHABILITATION ACT OF 1973, IF YOU NEED SPECIAL ASSISTANCE TO PARTICIPATE IN THIS MEETING, PLEASE CONTACT THE PLANNING AND BUILDING DEPARTMENT AT (760) 633-2710 AT LEAST 48 HOURS BEFORE THE MEETING IF DISABILITY ACCOMMODATIONS ARE NEEDED. Notice is hereby given that an Encinitas Housing Authority meeting will be held on Wednesday, March 9, 2016 at 5:00 p.m. for a public hearing regarding proposed amendments to the Section 8 Housing Choice Voucher (HCV) Program Administrative Plan. The proposed amendments to the Section 8 HCV Program Administrative Plan are currently available for review and comment at the City of Encinitas Planning & Building Department located at 505 S. Vulcan Ave., Encinitas, CA 92024 during regular business hours and on the City’s website at www.encinitasca.gov. The City of Encinitas Housing Authority receives federal housing funds annually from the U.S. Department of Housing and Urban Development (HUD) for its Section 8 HCV Program. Housing Authorities are required to develop and adopt a written Administrative Plan for overall management of the program. The purpose of the Administrative Plan is to establish local objectives and policies for carrying out the Section 8 HCV Program in a manner consistent with HUD requirements. The Administrative Plan, including proposed revisions, must be approved by the Housing Authority Board and submitted to HUD. ENVIRONMENTAL STATUS: The project is exempt from environmental review pursuant to the California Environmental Quality Act (CEQA). Please provide any comments to Kathy Noel at knoel@encinitasca.gov; or by mail to City of Encinitas, 505 S. Vulcan Ave., Encinitas, CA 92024. You may also provide comments at the Encinitas Housing Authority Board public hearing, scheduled on March 9, 2016 at 5pm at Encinitas City Hall. Please call (760) 633-2753 with any questions. 02/26/16 CN 18310

PUBLIC NOTICE CITY OF ENCINITAS AVAILABILITY OF REQUEST FOR VIDEO PRODUCTION SERVICES PROPOSAL The City of Encinitas is currently soliciting proposals for Video Production Services. The Request for Proposal can be obtained at City Hall, 505 South Vulcan Avenue, Encinitas, CA 92024 or online at the City’s website: www.encinitasca.gov under Bids & RFP’s. Completed proposals must be submitted to the City Clerk’s Office by 4:00 p.m. on March 31, 2016. The City of Encinitas hereby notifies all potential PROVIDERS that it will insure that in any Agreement entered into pursuant to this advertisement, minority business enterprises will be afforded full opportunity to submit proposals in response to this invitation and will not be discriminated against on the grounds of race, color or national origin in consideration for an award. The City of Encinitas reserves the right to reject any or all proposals, or waive any irregularities or technical deficiencies in any proposal. 02/26/16 CN 18309

CITY OF CARLSBAD PUBLIC NOTICE TO INTERESTED PARTIES: Please be advised that the City of Carlsbad is considering text and map amendments to its Local Coastal Program (LCP) as summarized below. This amendment is being proposed by the City of Carlsbad and is currently under review. This notice hereby opens a six week review period after which the Planning Commission and City Council will consider all comments and act on the proposed amendment. The Planning Commission and City Council hearings are expected to take place in the spring 2016, and will be duly noticed. Copies of the LCP amendment are available for review at the following locations: (1) Carlsbad Planning Division, 1635 Faraday Avenue; (2) City Clerk’s Office, 1200 Carlsbad Village Drive; (3) Carlsbad Main Library, 1775 Dove Lane; (4) Georgina Cole Library, 1250 Carlsbad Village Drive; and (5) the California Coastal Commission, 7575 Metropolitan Drive, Suite 103, San Diego, CA 92108-4402. PROPOSED LCP AMENDMENT SUMMARY LCPA 14-01 – VILLAGE AND BARRIO MASTER PLAN LCPA 14-01 has been prepared for the proposed Village and Barrio Master Plan, a proposed land use document specifically for the city’s downtown (Village) and the southerly adjacent Barrio. The Village and Barrio are located at the northwestern edge of the city, west of Interstate 5 and approximately between Buena Vista Lagoon and Tamarack Avenue. The planning area is mostly developed; a portion is in the Coastal Zone. Plan adoption would require several discretionary approvals. The proposed master plan consists of a vision plan, a regulating code, design guidelines, and an appendix. The plan proposes no development, but the vision portion identifies a number of ideas and objectives that could be implemented upon further and separate analysis and approval. The proposal would replace the current Village Master Plan and Design Manual applicable to the Village and the general zoning districts and standards applicable in the Barrio. LCPA 14-01 is proposed to enable consideration and approval of the following actions: 1. Adoption of the Village and Barrio Master Plan, which would (1) replace in the Village area the Village Master Plan and Design Manual and serve as the land use plan for the Village Area segment of the city’s Local Coastal Program and which would (2) serve area as the new zoning and land use document for the Barrio area, which is regulated presently by general city-wide zoning standards (note that the portion of the Barrio presently within the Coastal Zone would continue to be subject to the provisions of the Mello II segment); 2. Approval of amendments to the Zoning Ordinance map and text, primarily to recognize the proposed Village and Barrio Master Plan, including through new zoning designations for properties within the boundaries of the Village and Barrio Master Plan. The Zoning Ordinance is an implementing ordinance for the Local Coastal Program. Accordingly, this Local Coastal Program Amendment is necessary to ensure consistency between its proposed amended Zoning Ordinance and its Local Coastal Program; 3. Approval of amendments to the Local Coastal Program land use plan and zoning maps to recognize new land use and zoning designations for properties within the boundaries of the Village and Barrio Master Plan, and; 4. Minor revisions to the boundary between the Mello II and Village Area segments of the city’s Local Coastal Program so four properties now split by the boundary or adjacent to it will be fully within the Village Area segment. The draft of the Village and Barrio Master Plan may be accessed on the city website at www.carlsbadca.gov/villagebarrio and is available at the City of Carlsbad city clerk’s office, libraries, and planning division. The following information is attached to support LCPA 14-01: 1. A draft of the text changes to the Zoning Ordinance (Figure 1). 2. A project location map of the Village and Barrio (Figure 2). 3. Maps indicating changes to the city’s General Plan (Figure 3) and zoning (Figure 4) maps. Changes proposed to the Local Coastal Program land use and zoning maps are similar; essentially, the land use and zoning for all properties within the proposed Village and Barrio Master Plan boundary would change to “VB, Village Barrio.” 4. A map showing proposed boundary changes between the Mello II and Village Area segments (Figure 5). If you have any questions, please contact Scott Donnell in the Planning Division at (760) 602-4618 or scott.donnell@carlsbadca.gov. Written comments should be sent to the Planning Division at 1635 Faraday Avenue, Carlsbad, CA 92008. PUBLISH DATE: February 26, 2016 PUBLISH DATE FOR U-T SAN DIEGO: February 26, 2016 PUBLISH DATE FOR COAST NEWS: February 26, 2016 02/26/16 CN 18304

CITY OF ENCINITAS CITY COUNCIL LEGAL NOTICE OF PUBLIC HEARING By The Public Works Department PLACE OF MEETING: Council Chambers, Civic Center 505 South Vulcan Avenue Encinitas, CA 92024 THE ABOVE MENTIONED AGENCY IS AN EQUAL OPPORTUNITY PUBLIC ENTITY AND DOES NOT DISCRIMINATE ON THE BASIS OF RACE, COLOR, ETHNIC ORIGIN, NATIONAL ORIGIN, SEX, RELIGION, VETERANS STATUS OR PHYSICAL OR MENTAL DISABILITY IN EMPLOYMENT OR THE PROVISION OF SERVICE. IN COMPLIANCE WITH THE AMERICANS WITH DISABILITIES ACT/SECTION 504 REHABILITATION ACT OF 1973, IF YOU NEED SPECIAL ASSISTANCE TO PARTICIPATE IN THIS MEETING, PLEASE CONTACT THE ENGINEERING DIVISION AT (760) 633-2770. It is hereby given that a Public Hearing will be held on Wednesday, the 9th day of March, 2016, at 6 p.m., at the City Council Meeting to discuss the following proposal: • Adoption of Resolution No. 2016-20 establishing residential permit parking on Sea View Court and Pacific View Lane and a No Parking Zone on Seacrest Way, Sea View Court, and Pacific View Lane Between 10:00 p.m. and 5:00 a.m.
PROJECT DESCRIPTION: Issue parking permits to all residents and their guests on Sea View Court and Pacific View Lane and prohibit parking by non-residents during specific hours of the day/night. ENVIRONMENTAL STATUS: No impact. For further information, please contact Rob Blough, Traffic Engineer at (760) 633-2705 or by email at rblough@encinitasca.gov; or contact the Engineering Division of the Public Works Department at (760) 633-2770. 02/26/16 CN 18282

CITY OF ENCINITAS CITY COUNCIL LEGAL NOTICE OF PUBLIC HEARING By The Public Works Department PLACE OF MEETING: Council Chambers, Civic Center 505 South Vulcan Avenue Encinitas, CA 92024 THE ABOVE MENTIONED AGENCY IS AN EQUAL OPPORTUNITY PUBLIC ENTITY AND DOES NOT DISCRIMINATE ON THE BASIS OF RACE, COLOR, ETHNIC ORIGIN, NATIONAL ORIGIN, SEX, RELIGION, VETERANS STATUS OR PHYSICAL OR MENTAL DISABILITY IN EMPLOYMENT OR THE PROVISION OF SERVICE. IN COMPLIANCE WITH THE AMERICANS WITH DISABILITIES ACT/SECTION 504 REHABILITATION ACT OF 1973, IF YOU NEED SPECIAL ASSISTANCE TO PARTICIPATE IN THIS MEETING, PLEASE CONTACT THE ENGINEERING DIVISION AT (760) 633-2770. It is hereby given that a Public Hearing will be held on Wednesday, the 9th day of March, 2016, at 6 p.m., at the City Council Meeting to discuss the following proposal: • Adoption of Resolution No. 2016-27 establishing residential permit parking on Beechtree Drive, Elmbranch Drive, Witham Road, Walnutview Drive, and Hickoryhill Drive between Walnutview Drive and Crest Drive. PROJECT DESCRIPTION: Issue parking permits to all residents and their guests on the above mentioned streets and prohibit parking by non-residents during specific hours of the day/night. ENVIRONMENTAL STATUS: No impact. For further information, please contact Rob Blough, Traffic Engineer at (760) 633-2705 or by email at rblough@encinitasca.gov; or contact the Engineering Division of the Public Works Department at (760) 633-2770. Engineering is located at 505 South Vulcan Avenue, Encinitas, CA 92024. 02/26/16 CN 18281

CALIFORNIA STATE UNIVERSITY SAN MARCOS Legal Notice Notice of Public Hearings Public hearing to change the admissions criteria for kinesiology and nursing beginning in 2017-2018 to comply with CSU enrollment goals. What is being planned? Notice is hereby given that California State University San Marcos will hold public hearings to receive comments and evidence on the proposed change in admissions policies related to Kinesiology and Nursing. When and Where Tuesday, March 1 6:00 pm – 7:00 pm Governing Board Room SSC 1 Palomar College Wednesday, March 2 6:00 pm – 7:00 pm Room 3601 Mira Costa College Tuesday, March 8 6:00 pm – 7:00 pm Welcome Center (Craven Hall) California State University San Marcos Any person may present oral comments at the public hearings. Persons with similar concerns or opinions are encouraged to choose one representative to speak. Time limitations on presentations will be imposed. Availability of Documents The tentative supporting documents and Notice of Public Hearing that describes the proposed change and explains the need for the change will be distributed at these hearings and are available for review and copying by appointment on weekdays between 8 a.m. and 5 p.m. at the following address: California State University San MarcosCraven Hall 3700 (Cougar Central) 333 S Twin Oaks Valley Road San Marcos, CA 92096 The above referenced documents are also available on the CSUSM website www.csusm.edu/impaction Public Comment and Submittal of Evidence COMMENTS WILL BE ACCEPTED UNTIL 5 P.M. MONDAY, March 4th. Persons wishing to comment on the proposal are invited to submit their comments in writing to Graham Oberem, Provost and Vice President for Academic Affairs, at the above address or send them electronically to: impaction@csusm.edu. To be evaluated and considered by campus personnel and the CSU Chancellor’s Office, all written comments and evidence must be received by the campus by 5 p.m. on Monday, Marc 4th. Late submittal of written comments or evidence will not be allowed or accepted into the record for this matter without a showing of good cause for the delay. In no event will late submittal of written comments or evidence be allowed or accepted if any party would be unduly prejudiced by the late submittal or if staff or the campus would not have an adequate opportunity to review, consider and respond to the comments or evidence. Scope of Hearings and Hearings Procedures CSUSM proposes full program impaction for two academic majors: Kinesiology and Nursing. CSUSM would allow up to 5 percent of its enrolled new student class to be comprised of students who do not meet the applicable CSUSM impaction threshold but do meet the CSU eligibility threshold. This would allow the campus to admit a limited number of CSU-eligible students with promise or talent who would otherwise be denied based on impaction criteria. For More Information For additional information or to make an appointment to review the file, please email us at impaction@csusm.edu or visit www.csusm.edu/impaction. 02/12/16, 02/19/16, 02/26/16 CN 18235

NOTICE OF PREPARATION DRAFT PROGRAM ENVIRONMENTAL IMPACT REPORT FOR THE MCCLELLAN-PALOMAR AIRPORT MASTER PLAN CARLSBAD, SAN DIEGO COUNTY, CALIFORNIA FEBRUARY 29, 2016 NOTICE IS HEREBY GIVEN that the County of San Diego (County) is proposing to prepare a Program Environmental Impact Report (EIR) for the following project in accordance with Section 15082 of the California Environmental Quality Act (CEQA). The County owns and operates McClellan-Palomar Airport located within the municipal limits of the City of Carlsbad, and proposes a phased series of capital improvements in a new 20-year Master Plan. As the CEQA Lead Agency, the County is requesting input as to the scope and content of the environmental information that should be contained in the Program EIR for the purpose of conducting an environmental review of the new McClellan-Palomar Airport Master Plan. The Initial Study for this project is available for review and download on the Airport’s website: http://www.sandiegocounty.gov/content/sdc/dpw/airports/palomar/masterplan.html Hard copies are also available for in-office review at the Airport’s office located at: 2192 Palomar Airport Rd, Carlsbad, CA 92011, at the Carlsbad City Library, 1775 Dove Ln, Carlsbad, CA 92011, the San Marcos Branch Library at 2 Civic Center Drive, San Marcos, CA 92069, or the Vista Branch Library at 700 Eucalyptus Avenue, Vista, CA 92084. The County will hold a public scoping meeting to outline elements of the Master Plan, provide an opportunity to view exhibits, and discuss the Airport’s future with engineering and environmental staff. Written comments regarding the scope of analysis in the Program EIR will be accepted at the meeting. The meeting will be held on Monday, February 29, 2016, from 6 to 8 p.m. at 1635 Faraday Ave, Carlsbad CA 92008. Due to the time limits mandated by State law, responses should be sent at the earliest possible date, but no later than March 29, 2016, 5:00 p.m. Please send your comments to: County of San Diego, Department of Public Works, Attn: Cynthia Curtis, Environmental Planning Manager. 5510 Overland Ave, Suite 410, San Diego, CA 92123. Fax: (858) 694-3925, e-mail: Cynthia.Curtis@sdcounty.ca.gov PROJECT OVERVIEW: The McClellan-Airport Master Plan is a flexible, phased 20-year strategy to prioritize projects at the Airport that provide safety and operational enhancements. The Master Plan uses technical studies, forecast data, Federal Aviation Administration (FAA) design engineering standards, and public involvement to support the modernization of the airport while maximizing use of existing airport property. The Master Plan evaluated rehabilitation, development, and new construction projects that would be required to meet the design standards of a Modified C/D-III airport classification, and the projects are proposed to occur as demand or capacity is realized. The major objectives of the Modified C/D-III design for the airport include: meeting FAA-required safety areas around the runway and taxiways (requires shifting aircraft movement areas), maintaining a 150’-wide runway, installation of Engineered Materials Arresting System (EMAS) as a safety enhancement to stop aircraft in overrun situations, and improvements to the capacity and efficiency of landside (i.e. emergency services and passenger/visitor/administration) facilities. 02/26/16 CN 18280

T.S. No.: 2015-02772-CA A.P.N.:161-381-31-00 Property Address: 1440 Darwin Drive, Oceanside, CA 92056 NOTICE OF TRUSTEE’S SALE PURSUANT TO CIVIL CODE § 2923.3(a), THE SUMMARY OF INFORMATION REFERRED TO BELOW IS NOT ATTACHED TO THE RECORDED COPY OF THIS DOCUMENT BUT ONLY TO THE COPIES PROVIDED TO THE TRUSTOR. NOTE: THERE IS A SUMMARY OF THE INFORMATION IN THIS DOCUMENT ATTACHED 注:本文件包含一个信息摘要 참고사항: 본 첨부 문서에 정보 요약서가 있습니다 NOTA: SE ADJUNTA UN RESUMEN DE LA INFORMACIÓN DE ESTE DOCUMENTO TALA: MAYROONG BUOD NG IMPORMASYON SA DOKUMENTONG ITO NA NAKALAKIP LƯU Ý: KÈM THEO ĐÂY LÀ BẢN TRÌNH BÀY TÓM LƯỢC VỀ THÔNG TIN TRONG TÀI LIỆU NÀY IMPORTANT NOTICE TO PROPERTY OWNER: YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 10/26/2006. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. Trustor: Susan Shaffer, a single woman Duly Appointed Trustee: Western Progressive, LLC Recorded 11/06/2006 as Instrument No. 2006-0787131 in book —, page— and of Official Records in the office of the Recorder of San Diego County, California, Date of Sale: 04/01/2016 at 10:30 AM Place of Sale: AT THE ENTRANCE TO THE EAST COUNTY REGIONAL CENTER BY THE STATUE, 250 E. MAIN STREET, EL CAJON, CA 92020 Estimated amount of unpaid balance and other charges: $ 354,090.84 NOTICE OF TRUSTEE’S SALE WILL SELL AT PUBLIC AUCTION TO HIGHEST BIDDER FOR CASH, CASHIER’S CHECK DRAWN ON A STATE OR NATIONAL BANK, A CHECK DRAWN BY A STATE OR FEDERAL CREDIT UNION, OR A CHECK DRAWN BY A STATE OR FEDERAL SAVINGS AND LOAN ASSOCIATION, A SAVINGS ASSOCIATION OR SAVINGS BANK SPECIFIED IN SECTION 5102 OF THE FINANCIAL CODE AND AUTHORIZED TO DO BUSINESS IN THIS STATE: All right, title, and interest conveyed to and now held by the trustee in the hereinafter described property under and pursuant to a Deed of Trust described as: More fully described in said Deed of Trust. Street Address or other common designation of real property: 1440 Darwin Drive, Oceanside, CA 92056 A.P.N.: 161-381-31-00 The undersigned Trustee disclaims any liability for any incorrectness of the street address or other common designation, if any, shown above. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust. The total amount of the unpaid balance of the obligation secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of the Notice of Sale is: $ 354,090.84. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. The beneficiary of the Deed of Trust has executed and delivered to the undersigned a written request to commence foreclosure, and the undersigned caused a Notice of Default and Election to Sell to be recorded in the county where the real property is located. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on this property. NOTICE OF TRUSTEE’S SALE Note: Because the Beneficiary reserves the right to bid less than the total debt owed, it is possible that at the time of the sale the opening bid may be less than the total debt NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (866)-960-8299 or visit this Internet Web site http://www.altisource.com/MortgageServices/DefaultManagement/TrusteeServices.aspx using the file number assigned to this case 2015-02772-CA. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Date: February 19, 2016 Western Progressive, LLC, as Trustee for beneficiary C/o 30 Corporate Park, Suite 450 Irvine, CA 92606 Automated Sale Information Line: (866) 960-8299 http://www.altisource.com/MortgageServices/DefaultManagement/TrusteeServices.aspx For Non-Automated Sale Information, call: (866) 240-3530 Trustee Sale Assistant WESTERN PROGRESSIVE, LLC MAY BE ACTING AS A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED MAY BE USED FOR THAT 02/26/16, 03/04/16, 03/11/16 CN 18312

T.S. No. 15-37349 APN: 158-461-16-00 NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 2/15/2006. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. A public auction sale to the highest bidder for cash, cashier’s check drawn on a state or national bank, check drawn by a state or federal credit union, or a check drawn by a state or federal savings and loan association, or savings association, or savings bank specified in Section 5102 of the Financial Code and authorized to do business in this state will be held by the duly appointed trustee as shown below, of all right, title, and interest conveyed to and now held by the trustee in the hereinafter described property under and pursuant to a Deed of Trust described below. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust, with interest and late charges thereon, as provided in the note(s), advances, under the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee for the total amount (at the time of the initial publication of the Notice of Sale) reasonably estimated to be set forth below. The amount may be greater on the day of sale. Trustor: SERGIO CAMBEROS AND LUZ ELENA CAMBEROS, HUSBAND AND WIFE AS JOINT TENANTS Duly Appointed Trustee: LAW OFFICES OF LES ZIEVE Deed of Trust recorded 3/1/2006 as Instrument No. 2006-0144684 in book –, page — of Official Records in the office of the Recorder of San Diego County, California, Date of Sale:3/21/2016 at 10:30 AM Place of Sale: AT THE ENTRANCE TO THE EAST COUNTY REGIONAL CENTER BY STATUE, 250 E. MAIN STREET, EL CAJON, CA 92020 Estimated amount of unpaid balance and other charges: $393,595.43 Note: Because the Beneficiary reserves the right to bid less than the total debt owed, it is possible that at the time of the sale the opening bid may be less than the total debt owed. Street Address or other common designation of real property: 5130 MANDARIN DRIVE OCEANSIDE, CA 92056 Described as follows: As more fully described on said Deed of Trust. A.P.N #.: 158-461-16-00 The undersigned Trustee disclaims any liability for any incorrectness of the street address or other common designation, if any, shown above. If no street address or other common designation is shown, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first publication of this Notice of Sale. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (714) 848-9272 or visit this Internet Web site www.elitepostandpub.com, using the file number assigned to this case 15-37349. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Dated: 2/23/2016 Law Offices of Les Zieve, as Trustee 30 Corporate Park, Suite 450 Irvine, CA 92606 For Non-Automated Sale Information, call: (714) 848-7920 For Sale Information: (714) 848-9272 www.elitepostandpub.com
Christine O’Brien, Trustee Sale Officer THIS FIRM IS ATTEMPTING TO COLLECT A DEBT AND ANY INFORMATION WE OBTAINED WILL BE USED FOR THAT PURPOSE. EPP 16282 2/26, 3/4, 3/11/16 CN 18285

NOTICE OF TRUSTEE’S SALE TS No. CA-15-668203-BF Order No.: 150112855-CA-VOI YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 1/24/2007. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. A public auction sale to the highest bidder for cash, cashier’s check drawn on a state or national bank, check drawn by state or federal credit union, or a check drawn by a state or federal savings and loan association, or savings association, or savings bank specified in Section 5102 to the Financial Code and authorized to do business in this state, will be held by duly appointed trustee. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust, with interest and late charges thereon, as provided in the note(s), advances, under the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee for the total amount (at the time of the initial publication of the Notice of Sale) reasonably estimated to be set forth below. The amount may be greater on the day of sale. BENEFICIARY MAY ELECT TO BID LESS THAN THE TOTAL AMOUNT DUE. Trustor(s): ARLENE YATES, TRUSTEES OF THE YATES FAMILY TRUST UNDER DECLARATION OF TRUST DATED DECEMBER 13, 1990 Recorded: 1/31/2007 as Instrument No. 2007-0069999 of Official Records in the office of the Recorder of SAN DIEGO County, California; Date of Sale: 3/18/2016 at 10:00 AM Place of Sale: At the entrance to the East County Regional Center by the statue, located at 250 E. Main St., El Cajon, CA 92020 Amount of unpaid balance and other charges: $924,142.85 The purported property address is: 1634 RIVERVIEW DRIVE, FALLBROOK, CA 92028 Assessor’s Parcel No.: 102-600-57-00 NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call 916.939.0772 for information regarding the trustee’s sale or visit this Internet Web site http://www.qualityloan.com , using the file number assigned to this foreclosure by the Trustee: CA-15-668203-BF . Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. The undersigned Trustee disclaims any liability for any incorrectness of the property address or other common designation, if any, shown herein. If no street address or other common designation is shown, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first publication of this Notice of Sale. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. If the sale is set aside for any reason, the Purchaser at the sale shall be entitled only to a return of the deposit paid. The Purchaser shall have no further recourse against the Mortgagor, the Mortgagee, or the Mortgagee’s Attorney. If you have previously been discharged through bankruptcy, you may have been released of personal liability for this loan in which case this letter is intended to exercise the note holders right’s against the real property only. As required by law, you are hereby notified that a negative credit report reflecting on your credit record may be submitted to a credit report agency if you fail to fulfill the terms of your credit obligations. QUALITY MAY BE CONSIDERED A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT AND ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE. Date: Quality Loan Service Corporation 411 Ivy Street San Diego, CA 92101 619-645-7711 For NON SALE information only Sale Line: 916.939.0772 Or Login to: http://www.qualityloan.com Reinstatement Line: (866) 645-7711 Ext 5318 Quality Loan Service Corp. TS No.: CA-15-668203-BF IDSPub #0102330 2/26/2016 3/4/2016 3/11/2016 CN 18284

T.S. No. 15-34250 APN: 156-310-08-00 NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 4/21/2005. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. A public auction sale to the highest bidder for cash, cashier’s check drawn on a state or national bank, check drawn by a state or federal credit union, or a check drawn by a state or federal savings and loan association, or savings association, or savings bank specified in Section 5102 of the Financial Code and authorized to do business in this state will be held by the duly appointed trustee as shown below, of all right, title, and interest conveyed to and now held by the trustee in the hereinafter described property under and pursuant to a Deed of Trust described below. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust, with interest and late charges thereon, as provided in the note(s), advances, under the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee for the total amount (at the time of the initial publication of the Notice of Sale) reasonably estimated to be set forth below. The amount may be greater on the day of sale. Trustor: JIMMY D BURGESS, AND KATRINA L J BURGESS, HUSBAND AND WIFE AS JOINT TENANTS
Duly Appointed Trustee: LAW OFFICES OF LES ZIEVE Deed of Trust recorded 4/29/2005 as Instrument No. 2005-0358627 in book , page of Official Records in the office of the Recorder of San Diego County, California, Date of Sale:3/21/2016 at 10:30 AM Place of Sale: AT THE ENTRANCE TO THE EAST COUNTY REGIONAL CENTER BY STATUE, 250 E. MAIN STREET, EL CAJON, CA 92020 Estimated amount of unpaid balance and other charges: $597,020.89 Note: Because the Beneficiary reserves the right to bid less than the total debt owed, it is possible that at the time of the sale the opening bid may be less than the total debt owed. Street Address or other common designation of real property: 2883 WOODRIDGE CIRCLE CARLSBAD, CA 92008-1162 Described as follows: As more fully described on said Deed of Trust. A.P.N #.: 156-310-08-00 The undersigned Trustee disclaims any liability for any incorrectness of the street address or other common designation, if any, shown above. If no street address or other common designation is shown, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first publication of this Notice of Sale. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (714) 848-9272 or visit this Internet Web site www.elitepostandpub.com, using the file number assigned to this case 15-34250. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Dated: 2/19/2016 Law Offices of Les Zieve, as Trustee 30 Corporate Park, Suite 450 Irvine, CA 92606 For Non-Automated Sale Information, call: (714) 848-7920 For Sale Information: (714) 848-9272 ww.elitepostandpub.com
Christine O’Brien, Trustee Sale Officer THIS FIRM IS ATTEMPTING TO COLLECT A DEBT AND ANY INFORMATION WE OBTAINED WILL BE USED FOR THAT PURPOSE. EPP 16276 2/26, 3/4, 3/11/16 CN 18283

T.S. No. 031722-CA APN: 157-743-26-00 NOTICE OF TRUSTEE’S SALE Pursuant to CA Civil Code 2923.3 IMPORTANT NOTICE TO PROPERTY OWNER: YOU ARE IN DEFAULT UNDER A DEED OF TRUST, DATED 2/6/2006. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER On 3/22/2016 at 10:30 AM, CLEAR RECON CORP., as duly appointed trustee under and pursuant to Deed of Trust recorded 2/10/2006, as Instrument No. 2006-0101333, Page 10245, of Official Records in the office of the County Recorder of San Diego County, State of CALIFORNIA executed by: GEORGE PSILOPOULOS AND DIANA K PSILOPOULOS, HUSBAND AND WIFE AS COMMUNITY PROPERTY WILL SELL AT PUBLIC AUCTION TO HIGHEST BIDDER FOR CASH, CASHIER’S CHECK DRAWN ON A STATE OR NATIONAL BANK, A CHECK DRAWN BY A STATE OR FEDERAL CREDIT UNION, OR A CHECK DRAWN BY A STATE OR FEDERAL SAVINGS AND LOAN ASSOCIATION, SAVINGS ASSOCIATION, OR SAVINGS BANK SPECIFIED IN SECTION 5102 OF THE FINANCIAL CODE AND AUTHORIZED TO DO BUSINESS IN THIS STATE: AT THE ENTRANCE TO THE EAST COUNTY REGIONAL CENTER BY STATUE, 250 E. MAIN STREET, EL CAJON, CA 92020 all right, title and interest conveyed to and now held by it under said Deed of Trust in the property situated in said County and State described as: MORE FULLY DESCRIBED ON SAID DEED OF TRUST The street address and other common designation, if any, of the real property described above is purported to be: 507 SPRINGFIELD AVENUE OCEANSIDE, CALIFORNIA 92057 The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be held, but without covenant or warranty, express or implied, regarding title, possession, condition, or encumbrances, including fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust, to pay the remaining principal sums of the note(s) secured by said Deed of Trust. The total amount of the unpaid balance of the obligation secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of the Notice of Sale is: $448,886.28 If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. The beneficiary under said Deed of Trust heretofore executed and delivered to the undersigned a written Declaration of Default and Demand for Sale, and a written Notice of Default and Election to Sell. The undersigned caused said Notice of Default and Election to Sell to be recorded in the county where the real property is located. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (844) 477-7869 or visit this Internet Web site WWW.STOXPOSTING.COM, using the file number assigned to this case 031722-CA. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. FOR SALES INFORMATION: (844) 477-7869 CLEAR RECON CORP. 4375 Jutland Drive Suite 200 San Diego, California 92117 02/26/16, 03/04/16, 03/11/16 CN 18279

NOTICE OF TRUSTEE’S SALE TS No. CA-15-692097-AB Order No.: 730-1508113-70 YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 11/4/2005. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. A public auction sale to the highest bidder for cash, cashier’s check drawn on a state or national bank, check drawn by state or federal credit union, or a check drawn by a state or federal savings and loan association, or savings association, or savings bank specified in Section 5102 to the Financial Code and authorized to do business in this state, will be held by duly appointed trustee. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust, with interest and late charges thereon, as provided in the note(s), advances, under the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee for the total amount (at the time of the initial publication of the Notice of Sale) reasonably estimated to be set forth below. The amount may be greater on the day of sale. BENEFICIARY MAY ELECT TO BID LESS THAN THE TOTAL AMOUNT DUE. Trustor(s): Sabrina R. Ruminer, a married woman, as her sole and separate property Recorded: 11/10/2005 as Instrument No. 2005-0981344 of Official Records in the office of the Recorder of SAN DIEGO County, California; Date of Sale: 3/18/2016 at 10:30AM Place of Sale: At the front entrance to the building located at 321 N. Nevada Street Oceanside, California 92054 Amount of unpaid balance and other charges: $593,523.91 The purported property address is: 4230 VIA CLEMENTE, OCEANSIDE, CA 92057 Assessor’s Parcel No.: 160-592-06-00 NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call 888-988-6736 for information regarding the trustee’s sale or visit this Internet Web site http://www.qualityloan.com , using the file number assigned to this foreclosure by the Trustee: CA-15-692097-AB . Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. The undersigned Trustee disclaims any liability for any incorrectness of the property address or other common designation, if any, shown herein. If no street address or other common designation is shown, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first publication of this Notice of Sale. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. If the sale is set aside for any reason, the Purchaser at the sale shall be entitled only to a return of the deposit paid. The Purchaser shall have no further recourse against the Mortgagor, the Mortgagee, or the Mortgagee’s Attorney. If you have previously been discharged through bankruptcy, you may have been released of personal liability for this loan in which case this letter is intended to exercise the note holders right’s against the real property only. As required by law, you are hereby notified that a negative credit report reflecting on your credit record may be submitted to a credit report agency if you fail to fulfill the terms of your credit obligations. QUALITY MAY BE CONSIDERED A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT AND ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE. Date: Quality Loan Service Corporation 411 Ivy Street San Diego, CA 92101 619-645-7711 For NON SALE information only Sale Line: 888-988-6736 Or Login to: http://www.qualityloan.com Reinstatement Line: (866) 645-7711 Ext 5318 Quality Loan Service Corp. TS No.: CA-15-692097-AB IDSPub #0101379 2/26/2016 3/4/2016 3/11/2016 CN 18277

Batch ID: Foreclosure HOA 44890-OP45-HOA APN: See Exhibit “A” Property Address: 333 N. Meyers St., Oceanside, CA 92054 NOTICE OF TRUSTEE’S SALE WARNING! YOU ARE IN DEFAULT UNDER A NOTICE OF DELINQUENT ASSESSMENT DATED . UNLESS YOU TAKE ACTION TO PROTECT YOUR TIMESHARE ESTATE, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDINGS AGAINST YOU, YOU SHOULD CONTACT A LAWYER. Exhibit “A” is attached hereto and made a part hereof. Date of Sale: 03/18/16 Time of Sale: 10:30 AM Place of Sale:At the entrance to the East County Regional Center by statue, 250 E. Main Street, El Cajon, CA 92020 First American Title Insurance Company, as the duly appointed Trustee under and pursuant to Notice of Delinquent Assessment, for each property held by the Owner(s), as shown on the Notice of Default and Election to Sell, as each document is duly recorded in the Official Records of San Diego County, CALIFORNIA, all as shown on Exhibit “A”, will sell at public auction for cash, lawful money of the United States of America, (a cashier’s check payable to said Trustee drawn on a state or national bank, a state or federal credit union, or a state or federal savings and loan association, or savings bank as specified in section 5102 of the Financial Code and authorized to do business in this state) all that right, title and interest conveyed to and now held by it under said Notice of Delinquent Assessment, the property situated in said County and State to wit: Those certain Timeshare Estates as described in the Covenants, Conditions and Restrictions Recorded on August 2, 2006 as Instrument No. 2006-0547090 of Official Records of San Diego County, California and in particular that certain timeshare interval commonly described as shown on Exhibit “A”. The Property Address is: 333 N. Meyers St., Oceanside, CA 92054. The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be made, without covenant or warranty, expressed or implied, as to title, possession, or encumbrances, to pay the remaining default amount under said Notice of Delinquent Assessment, with interest thereon as provided in said notice, accrued interest thereon to the date of sale, estimated fees, charges, and expenses of the Trustee, as shown on Exhibit “A” (Estimated). Accrued Interest and additional advances, if any, will increase this figure prior to sale. This foreclosure is for a default on delinquent assessments. The claimant, Oceanside Vacation Owners Association, Inc. a California nonprofit mutual benefit corporation, under said Notice of Delinquent Assessment heretofore executed and delivered to the undersigned a written Declaration of Default and Demand for Sale, and a written Notice of Default and Election to Sell. The undersigned caused said Notice of Default and Election to Sell to be recorded in the county where the real property is located and more than three months have elapsed since such recordation. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call 888-334-7678 for information regarding the trustee’s sale] or visit this Internet Web site www.feillc.com, using the file number assigned to this case ______________, Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. PUBLISH: ________ Exhibit A T.S. Number Contract Number Points / Frequency APN Trustor(s) Lien Dated Date Recorded & Instrument No. Notice of Default Date Recorded & Instrument No. Default Amount Estimated Cost 3374401 1030702427 168000 / E 147-075-08-00 David J. Hossler, and the unrecorded interest of the spouse of David J. Hossler, if any 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $894.18 $600.00 3374402 1030707566 413000 / A 147-075-08-00 Phillip B. Dawson 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $3,353.87 $600.00 3374403 1030709158 126000 / A 147-075-08-00 TVC Inc. a company duly organized and existing under and by virtue of the laws of the State of Wyoming 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $2,101.88 $600.00 3374404 1030801104 308000 / A 147-075-08-00 Eric P Barnett and Nicole R Barnett 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $747.92 $600.00 3374405 1030802037 210000 / A 147-075-08-00 Mukkatira C. Madayya and Sumitha Madayya 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $829.99 $600.00 3374406 1030805253 119000 / O 145-075-08-00 Elliot’s World, LLC, a Delaware Limited Liability Company 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $2,025.75 $600.00 3374407 1030807150 210000 / A 147-075-08-00 JEAN ROSE and The Fireside Registry, LLC, a Delaware Limited Liability Company 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $2,136.80 $600.00 3374408 1030901250 154000 / E 147-075-08-00 RAMONA MAIORELLA 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $1,566.98 $600.00 3374409 1120604715 66000 / A 147-075-08-00 Falco Administration, LLC 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $1,010.48 $600.00 3374410 1120701057 154000 / A 147-075-08-00 C W Consulting Services, LLC. 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $2,812.02 $600.00 3374412 1120701925 154000 / A 147-075-08-00 TIMOTHY P SCHMIDT and KERRY J SCHMIDT 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $2,879.81 $600.00 3374413 1120703624 84000 / E 147-075-08-00 Eden Frye 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $682.15 $600.00 3374414 1120705074 84000 / O 147-075-08-00 CLEMENTINE VENTURA, and the unrecorded interest of the spouse of CLEMENTINE VENTURA, if any 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $1,706.46 $600.00 3374415 1230709206 154000 / A 147-075-08-00 Eva W Jenkins, and the unrecorded interest of the spouse of EVA W JENKINS, if any 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $1,250.54 $600.00 3374416 1230709602 210000 / E 147-075-08-00 Debra Jennings-Roberson and Michael Roberson 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $529.38 $600.00 3374585 410643613 413000 / A 147-075-08-00 “The Fireside Registry, LLC, a Delaware Limited Liability Company” 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $5,192.72 $600.00 3374418 410706501 420000 / A 147-075-08-00 “ST Hamm Management, a Delaware Limited Liability” 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $7,150.85 $600.00 3374419 410710412 707000 / A 147-075-08-00 SHARON GRUBB 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $3,545.54 $600.00 3374420 430705863 40000 / A 147-075-08-00 United Kingdom Travel, LLC, a New Mexico Limited Liability Company 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $516.54 $600.00 3374421 430706242 210000 / E 147-075-08-00 VVT, Inc. 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $1,751.56 $600.00 3374422 430807222 105000 / O 147-075-08-00 The Golden Grill LLC, a Delaware Limited Company 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $886.69 $600.00 3374423 570700385 168000 / O 147-075-08-00 CRAIG BRYANT 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $509.53 $600.00 3374424 580649085 210000 / O 147-075-08-00 Mark Lovecchio and Nikia Lovecchio and Nathan Reese and Delilah Reese 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $536.58 $600.00 3374425 580654895 154000 / A 147-075-08-00 “Vacation Luxury Plus (V.L.P) Inc., a Canadian Corporation” 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $1,830.68 $600.00 3374426 580706059 168000 / E 147-075-08-00 BRIAN KELLY and KAREN KELLY 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $1,746.64 $600.00 3374428 730800406 308000 / A 147-075-08-00 Raymond V. Dunn 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $2,817.62 $600.00 3374429 730807039 105000 / A 147-075-08-00 “Van Drivers Consulting, LLC, a Delaware Limited Liability Company” 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $1,751.56 $600.00 3374430 730902137 175000 / O 147-075-08-00 GEORGE BARKAS 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $1,459.36 $600.00 3374431 730902707 300000 / A 147-075-08-00 Shon Holloway 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $760.75 $600.00 3374432 731008934 212000 / A 147-075-08-00 Timeshare Trade Ins. LLC, 10/02/15 10-14-2015 / 2015-0538229 11-19-2015 / 2015-0600711 $950.79 $600.00 FEI # 1081.00484 02/26/16, 03/04/16, 03/11/16 CN 18276

APN: 103-040-33-00 TS No: CA05001485-15-1 TO No: 8594909 NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED April 18, 2007. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDINGS AGAINST YOU, YOU SHOULD CONTACT A LAWYER. On March 15, 2016 at 10:30 AM, at the entrance to the East County Regional Center by statue, 250 E. Main Street, El Cajon, CA 92020, MTC Financial Inc. dba Trustee Corps, as the duly Appointed Trustee, under and pursuant to the power of sale contained in that certain Deed of Trust recorded on May 2, 2007, as Instrument No. 2007-0299198, of official records in the Office of the Recorder of San Diego County, California, executed by CAROL A MUNOZ, TRUSTEE OF THE CAROL A MUNOZ FAMILY TRUST DATED MARCH 20, 1995, as Trustor(s), in favor of MORTGAGE ELECTRONIC REGISTRATION SYSTEMS, INC. as nominee for COUNTRYWIDE HOME LOANS, INC. as Beneficiary, WILL SELL AT PUBLIC AUCTION TO THE HIGHEST BIDDER, in lawful money of the United States, all payable at the time of sale, that certain property situated in said County, California describing the land therein as: AS MORE FULLY DESCRIBED IN SAID DEED OF TRUST The property heretofore described is being sold “as is”. The street address and other common designation, if any, of the real property described above is purported to be: 832 DE LUZ ROAD, FALLBROOK, CA 92028-8941 The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be made without covenant or warranty, express or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the Note(s) secured by said Deed of Trust, with interest thereon, as provided in said Note(s), advances if any, under the terms of the Deed of Trust, estimated fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust. The total amount of the unpaid balance of the obligations secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of this Notice of Trustee’s Sale is estimated to be $167,019.12 (Estimated). However, prepayment premiums, accrued interest and advances will increase this figure prior to sale. Beneficiary’s bid at said sale may include all or part of said amount. In addition to cash, the Trustee will accept a cashier’s check drawn on a state or national bank, a check drawn by a state or federal credit union or a check drawn by a state or federal savings and loan association, savings association or savings bank specified in Section 5102 of the California Financial Code and authorized to do business in California, or other such funds as may be acceptable to the Trustee. In the event tender other than cash is accepted, the Trustee may withhold the issuance of the Trustee’s Deed Upon Sale until funds become available to the payee or endorsee as a matter of right. The property offered for sale excludes all funds held on account by the property receiver, if applicable. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee and the successful bidder shall have no further recourse. Notice to Potential Bidders If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a Trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a Trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same Lender may hold more than one mortgage or Deed of Trust on the property. Notice to Property Owner The sale date shown on this Notice of Sale may be postponed one or more times by the Mortgagee, Beneficiary, Trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about Trustee Sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call In Source Logic at 702-659-7766 for information regarding the Trustee’s Sale or visit the Internet Web site address listed below for information regarding the sale of this property, using the file number assigned to this case, CA05001485-15-1. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Date: February 9, 2016 MTC Financial Inc. dba Trustee Corps TS No. CA05001485-15-1 17100 Gillette Ave Irvine, CA 92614 949-252-8300 TDD: 866-660-4288 Stephanie Hoy, Authorized Signatory SALE INFORMATION CAN BE OBTAINED ON LINE AT www.insourcelogic.com FOR AUTOMATED SALES INFORMATION PLEASE CALL: In Source Logic AT 702-659-7766 MTC Financial Inc. dba Trustee Corps MAY BE ACTING AS A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED MAY BE USED FOR THAT PURPOSE. ORDER NO. CA16-000463-1, PUB DATES: 02/19/2016, 02/26/2016, 03/04/2016 CN 18250

NOTICE OF TRUSTEE’S SALE TS No. CA-11-420008-EV Order No.: 709106 YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 3/9/2010. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. A public auction sale to the highest bidder for cash, cashier’s check drawn on a state or national bank, check drawn by state or federal credit union, or a check drawn by a state or federal savings and loan association, or savings association, or savings bank specified in Section 5102 to the Financial Code and authorized to do business in this state, will be held by duly appointed trustee. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust, with interest and late charges thereon, as provided in the note(s), advances, under the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee for the total amount (at the time of the initial publication of the Notice of Sale) reasonably estimated to be set forth below. The amount may be greater on the day of sale. BENEFICIARY MAY ELECT TO BID LESS THAN THE TOTAL AMOUNT DUE. Trustor(s): CHRISTOPHER D GETCHELL AND RHONDA GETCHELL, HUSBAND AND WIFE Recorded: 3/16/2010 as Instrument No. 2010-0128208 of Official Records in the office of the Recorder of SAN DIEGO County, California; Date of Sale: 3/11/2016 at 10:30AM Place of Sale: At the front entrance to the building located at 321 N. Nevada Street Oceanside, California 92054 Amount of unpaid balance and other charges: $390,649.58 The purported property address is: 942 N MAIN AVE, FALLBROOK, CA 92028 Assessor’s Parcel No.: 103-040-43-00 NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call 888-988-6736 for information regarding the trustee’s sale or visit this Internet Web site http://www.qualityloan.com , using the file number assigned to this foreclosure by the Trustee: CA-11-420008-EV . Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. The undersigned Trustee disclaims any liability for any incorrectness of the property address or other common designation, if any, shown herein. If no street address or other common designation is shown, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first publication of this Notice of Sale. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. If the sale is set aside for any reason, the Purchaser at the sale shall be entitled only to a return of the deposit paid. The Purchaser shall have no further recourse against the Mortgagor, the Mortgagee, or the Mortgagee’s Attorney. If you have previously been discharged through bankruptcy, you may have been released of personal liability for this loan in which case this letter is intended to exercise the note holders right’s against the real property only. As required by law, you are hereby notified that a negative credit report reflecting on your credit record may be submitted to a credit report agency if you fail to fulfill the terms of your credit obligations. QUALITY MAY BE CONSIDERED A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT AND ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE. Date: Quality Loan Service Corporation 411 Ivy Street San Diego, CA 92101 619-645-7711 For NON SALE information only Sale Line: 888-988-6736 Or Login to: http://www.qualityloan.com Reinstatement Line: (866) 645-7711 Ext 5318 Quality Loan Service Corp. TS No.: CA-11-420008-EV IDSPub #0100871 2/19/2016 2/26/2016 3/4/2016 CN 18249

NOTICE OF TRUSTEE’S SALE TS No. CA-15-690745-BF Order No.: 730-1507458-70 YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 1/4/2012. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. A public auction sale to the highest bidder for cash, cashier’s check drawn on a state or national bank, check drawn by state or federal credit union, or a check drawn by a state or federal savings and loan association, or savings association, or savings bank specified in Section 5102 to the Financial Code and authorized to do business in this state, will be held by duly appointed trustee. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust, with interest and late charges thereon, as provided in the note(s), advances, under the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee for the total amount (at the time of the initial publication of the Notice of Sale) reasonably estimated to be set forth below. The amount may be greater on the day of sale. BENEFICIARY MAY ELECT TO BID LESS THAN THE TOTAL AMOUNT DUE. Trustor(s): Kyle A Bloom, a married man as his sole and separate property Recorded: 1/11/2012 as Instrument No. 2012-0015675 of Official Records in the office of the Recorder of SAN DIEGO County, California; Date of Sale: 3/11/2016 at 10:00 AM Place of Sale: At the entrance to the East County Regional Center by the statue, located at 250 E. Main St., El Cajon, CA 92020 Amount of unpaid balance and other charges: $270,839.17 The purported property address is: 1111 PALOMINO ROAD, FALLBROOK, CA 92028 Assessor’s Parcel No.: 106-051-01-00 NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call 916.939.0772 for information regarding the trustee’s sale or visit this Internet Web site http://www.qualityloan.com , using the file number assigned to this foreclosure by the Trustee: CA-15-690745-BF . Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. The undersigned Trustee disclaims any liability for any incorrectness of the property address or other common designation, if any, shown herein. If no street address or other common designation is shown, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first publication of this Notice of Sale. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. If the sale is set aside for any reason, the Purchaser at the sale shall be entitled only to a return of the deposit paid. The Purchaser shall have no further recourse against the Mortgagor, the Mortgagee, or the Mortgagee’s Attorney. If you have previously been discharged through bankruptcy, you may have been released of personal liability for this loan in which case this letter is intended to exercise the note holders right’s against the real property only. As required by law, you are hereby notified that a negative credit report reflecting on your credit record may be submitted to a credit report agency if you fail to fulfill the terms of your credit obligations. QUALITY MAY BE CONSIDERED A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT AND ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE. Date: Quality Loan Service Corporation 411 Ivy Street San Diego, CA 92101 619-645-7711 For NON SALE information only Sale Line: 916.939.0772 Or Login to: http://www.qualityloan.com Reinstatement Line: (866) 645-7711 Ext 5318 Quality Loan Service Corp. TS No.: CA-15-690745-BF IDSPub #0100730 2/19/2016 2/26/2016 3/4/2016 CN 18248

T.S. No. 15-37088 APN: 161-591-14-00 NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED 10/7/2004. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER. A public auction sale to the highest bidder for cash, cashier’s check drawn on a state or national bank, check drawn by a state or federal credit union, or a check drawn by a state or federal savings and loan association, or savings association, or savings bank specified in Section 5102 of the Financial Code and authorized to do business in this state will be held by the duly appointed trustee as shown below, of all right, title, and interest conveyed to and now held by the trustee in the hereinafter described property under and pursuant to a Deed of Trust described below. The sale will be made, but without covenant or warranty, expressed or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the note(s) secured by the Deed of Trust, with interest and late charges thereon, as provided in the note(s), advances, under the terms of the Deed of Trust, interest thereon, fees, charges and expenses of the Trustee for the total amount (at the time of the initial publication of the Notice of Sale) reasonably estimated to be set forth below. The amount may be greater on the day of sale. Trustor: CHARLES TURNER, AN UNMARRIED MAN Duly Appointed Trustee: LAW OFFICES OF LES ZIEVE Deed of Trust recorded 10/18/2004 as Instrument No. 2004-0984492 in book , page of Official Records in the office of the Recorder of San Diego County, California, Date of Sale:3/7/2016 at 10:30 AM Place of Sale: AT THE ENTRANCE TO THE EAST COUNTY REGIONAL CENTER BY STATUE, 250 E. MAIN STREET, EL CAJON, CA 92020 Estimated amount of unpaid balance and other charges: $52,488.18 Note: Because the Beneficiary reserves the right to bid less than the total debt owed, it is possible that at the time of the sale the opening bid may be less than the total debt owed.Street Address or other common designation of real property: 1627 CORTE VERANO OCEANSIDE, California 92056 Described as follows: As more fully described in said Deed of Trust A.P.N #.: 161-591-14-00 The undersigned Trustee disclaims any liability for any incorrectness of the street address or other common designation, if any, shown above. If no street address or other common designation is shown, directions to the location of the property may be obtained by sending a written request to the beneficiary within 10 days of the date of first publication of this Notice of Sale. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (714) 848-9272 or visit this Internet Web site www.elitepostandpub.com, using the file number assigned to this case 15-37088. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Dated: 2/5/2016 Law Offices of Les Zieve, as Trustee 30 Corporate Park, Suite 450 Irvine, CA 92606 For Non-Automated Sale Information, call: (714) 848-7920 For Sale Information: (714) 848-9272 www.elitepostandpub.com Christine O’Brien, Trustee Sale Officer THIS FIRM IS ATTEMPTING TO COLLECT A DEBT AND ANY INFORMATION WE OBTAINED WILL BE USED FOR THAT PURPOSE. EPP 16024 2/12, 2/19, 2/26/16 CN 18234

T.S. No. 026924-CA APN: 259-222-16-41 NOTICE OF TRUSTEE’S SALE Pursuant to CA Civil Code 2923.3 IMPORTANT NOTICE TO PROPERTY OWNER: YOU ARE IN DEFAULT UNDER A DEED OF TRUST, DATED 4/8/2005. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER On 3/8/2016 at 10:30 AM, CLEAR RECON CORP., as duly appointed trustee under and pursuant to Deed of Trust recorded 4/20/2005, as Instrument No. 2005-0329304, of Official Records in the office of the County Recorder of San Diego County, State of CALIFORNIA executed by: KAREN L KOBLENTZ AN UNMARRIED WOMAN WILL SELL AT PUBLIC AUCTION TO HIGHEST BIDDER FOR CASH, CASHIER’S CHECK DRAWN ON A STATE OR NATIONAL BANK, A CHECK DRAWN BY A STATE OR FEDERAL CREDIT UNION, OR A CHECK DRAWN BY A STATE OR FEDERAL SAVINGS AND LOAN ASSOCIATION, SAVINGS ASSOCIATION, OR SAVINGS BANK SPECIFIED IN SECTION 5102 OF THE FINANCIAL CODE AND AUTHORIZED TO DO BUSINESS IN THIS STATE: AT THE ENTRANCE TO THE EAST COUNTY REGIONAL CENTER BY STATUE, 250 E. MAIN STREET, EL CAJON, CA 92020all right, title and interest conveyed to and now held by it under said Deed of Trust in the property situated in said County and State described as: MORE FULLY DESCRIBED ON SAID DEED OF TRUST The street address and other common designation, if any, of the real property described above is purported to be: 1841 BELLE GROVE RD ENCINITAS, CA 92024 The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be held, but without covenant or warranty, express or implied, regarding title, possession, condition, or encumbrances, including fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust, to pay the remaining principal sums of the note(s) secured by said Deed of Trust. The total amount of the unpaid balance of the obligation secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of the Notice of Sale is: $457,121.36 If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. The beneficiary under said Deed of Trust heretofore executed and delivered to the undersigned a written Declaration of Default and Demand for Sale, and a written Notice of Default and Election to Sell. The undersigned caused said Notice of Default and Election to Sell to be recorded in the county where the real property is located. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (844) 477-7869 or visit this Internet Web site WWW.STOXPOSTING.COM, using the file number assigned to this case 026924-CA. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. FOR SALES INFORMATION: (844) 477-7869 CLEAR RECON CORP. 4375 Jutland Drive Suite 200 San Diego, California 92117 02/12/16, 02/19/16, 02/26/16 CN 18222

T.S. No. 026792-CA APN: 258-271-28-00 NOTICE OF TRUSTEE’S SALE Pursuant to CA Civil Code 2923.3 IMPORTANT NOTICE TO PROPERTY OWNER: YOU ARE IN DEFAULT UNDER A DEED OF TRUST, DATED 2/1/2006. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDING AGAINST YOU, YOU SHOULD CONTACT A LAWYER On 3/8/2016 at 10:30 AM, CLEAR RECON CORP., as duly appointed trustee under and pursuant to Deed of Trust recorded 2/7/2006, as Instrument No. 2006-0090661, of Official Records in the office of the County Recorder of San Diego County, State of CALIFORNIA executed by: DENISE K SCHMIDT AN UNMARRIED WOMAN WILL SELL AT PUBLIC AUCTION TO HIGHEST BIDDER FOR CASH, CASHIER’S CHECK DRAWN ON A STATE OR NATIONAL BANK, A CHECK DRAWN BY A STATE OR FEDERAL CREDIT UNION, OR A CHECK DRAWN BY A STATE OR FEDERAL SAVINGS AND LOAN ASSOCIATION, SAVINGS ASSOCIATION, OR SAVINGS BANK SPECIFIED IN SECTION 5102 OF THE FINANCIAL CODE AND AUTHORIZED TO DO BUSINESS IN THIS STATE: AT THE ENTRANCE TO THE EAST COUNTY REGIONAL CENTER BY STATUE, 250 E. MAIN STREET, EL CAJON, CA 92020 all right, title and interest conveyed to and now held by it under said Deed of Trust in the property situated in said County and State described as: MORE FULLY DESCRIBED ON SAID DEED OF TRUST The street address and other common designation, if any, of the real property described above is purported to be: 1062 GOLDEN RD ENCINITAS, CA 92024 The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be held, but without covenant or warranty, express or implied, regarding title, possession, condition, or encumbrances, including fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust, to pay the remaining principal sums of the note(s) secured by said Deed of Trust. The total amount of the unpaid balance of the obligation secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of the Notice of Sale is: $981,276.25 If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee, and the successful bidder shall have no further recourse. The beneficiary under said Deed of Trust heretofore executed and delivered to the undersigned a written Declaration of Default and Demand for Sale, and a written Notice of Default and Election to Sell. The undersigned caused said Notice of Default and Election to Sell to be recorded in the county where the real property is located. NOTICE TO POTENTIAL BIDDERS: If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same lender may hold more than one mortgage or deed of trust on the property. NOTICE TO PROPERTY OWNER: The sale date shown on this notice of sale may be postponed one or more times by the mortgagee, beneficiary, trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about trustee sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call (844) 477-7869 or visit this Internet Web site WWW.STOXPOSTING.COM, using the file number assigned to this case 026792-CA. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. FOR SALES INFORMATION: (844) 477-7869 CLEAR RECON CORP. 4375 Jutland Drive Suite 200 San Diego, California 92117 02/12/16, 02/19/16, 02/26/16 CN 18221

APN: 263-622-29-00 TS No: CA08001211-15-1 TO No: 8534974 NOTICE OF TRUSTEE’S SALE YOU ARE IN DEFAULT UNDER A DEED OF TRUST DATED November 16, 2007. UNLESS YOU TAKE ACTION TO PROTECT YOUR PROPERTY, IT MAY BE SOLD AT A PUBLIC SALE. IF YOU NEED AN EXPLANATION OF THE NATURE OF THE PROCEEDINGS AGAINST YOU, YOU SHOULD CONTACT A LAWYER. On March 18, 2016 at 09:00 AM, Entrance of the East County Regional Center, East County Regional Center, 250 E. Main Street, El Cajon, CA 92020, MTC Financial Inc. dba Trustee Corps, as the duly Appointed Trustee, under and pursuant to the power of sale contained in that certain Deed of Trust Recorded on November 21, 2007 as Instrument No. 2007-0731687 of official records in the Office of the Recorder of San Diego County, California, executed by MARC D. LAIR, A MARRIED MAN, AS HIS SOLE AND SEPARATE PROPERTY, as Trustor(s), in favor of WASHINGTON MUTUAL BANK, FA as Beneficiary, WILL SELL AT PUBLIC AUCTION TO THE HIGHEST BIDDER, in lawful money of the United States, all payable at the time of sale, that certain property situated in said County, California describing the land therein as: AS MORE FULLY DESCRIBED IN SAID DEED OF TRUST The property heretofore described is being sold “as is”. The street address and other common designation, if any, of the real property described above is purported to be: 239 LA BARRANCA DRIVE, SOLANA BEACH, CA 92075 The undersigned Trustee disclaims any liability for any incorrectness of the street address and other common designation, if any, shown herein. Said sale will be made without covenant or warranty, express or implied, regarding title, possession, or encumbrances, to pay the remaining principal sum of the Note(s) secured by said Deed of Trust, with interest thereon, as provided in said Note(s), advances if any, under the terms of the Deed of Trust, estimated fees, charges and expenses of the Trustee and of the trusts created by said Deed of Trust. The total amount of the unpaid balance of the obligations secured by the property to be sold and reasonable estimated costs, expenses and advances at the time of the initial publication of this Notice of Trustee’s Sale is estimated to be $900,502.32 (Estimated). However, prepayment premiums, accrued interest and advances will increase this figure prior to sale. Beneficiary’s bid at said sale may include all or part of said amount. In addition to cash, the Trustee will accept a cashier’s check drawn on a state or national bank, a check drawn by a state or federal credit union or a check drawn by a state or federal savings and loan association, savings association or savings bank specified in Section 5102 of the California Financial Code and authorized to do business in California, or other such funds as may be acceptable to the Trustee. In the event tender other than cash is accepted, the Trustee may withhold the issuance of the Trustee’s Deed Upon Sale until funds become available to the payee or endorsee as a matter of right. The property offered for sale excludes all funds held on account by the property receiver, if applicable. If the Trustee is unable to convey title for any reason, the successful bidder’s sole and exclusive remedy shall be the return of monies paid to the Trustee and the successful bidder shall have no further recourse. Notice to Potential Bidders If you are considering bidding on this property lien, you should understand that there are risks involved in bidding at a Trustee auction. You will be bidding on a lien, not on the property itself. Placing the highest bid at a Trustee auction does not automatically entitle you to free and clear ownership of the property. You should also be aware that the lien being auctioned off may be a junior lien. If you are the highest bidder at the auction, you are or may be responsible for paying off all liens senior to the lien being auctioned off, before you can receive clear title to the property. You are encouraged to investigate the existence, priority, and size of outstanding liens that may exist on this property by contacting the county recorder’s office or a title insurance company, either of which may charge you a fee for this information. If you consult either of these resources, you should be aware that the same Lender may hold more than one mortgage or Deed of Trust on the property. Notice to Property Owner The sale date shown on this Notice of Sale may be postponed one or more times by the Mortgagee, Beneficiary, Trustee, or a court, pursuant to Section 2924g of the California Civil Code. The law requires that information about Trustee Sale postponements be made available to you and to the public, as a courtesy to those not present at the sale. If you wish to learn whether your sale date has been postponed, and, if applicable, the rescheduled time and date for the sale of this property, you may call Auction.com at 800.280.2832 for information regarding the Trustee’s Sale or visit the Internet Web site address www.Auction.com for information regarding the sale of this property, using the file number assigned to this case, CA08001211-15-1. Information about postponements that are very short in duration or that occur close in time to the scheduled sale may not immediately be reflected in the telephone information or on the Internet Web site. The best way to verify postponement information is to attend the scheduled sale. Date: February 3, 2016 MTC Financial Inc. dba Trustee Corps TS No. CA08001211-15-1 17100 Gillette Ave, Irvine, CA 92614 949-252-8300 TDD: 866-660-4288 Miguel Ochoa, Authorized Signatory SALE INFORMATION CAN BE OBTAINED ONLINE AT www.Auction.com FOR AUTOMATED SALES INFORMATION PLEASE CALL: Auction.com at 800.280.2832 MTC Financial Inc. dba Trustee Corps MAY BE ACTING AS A DEBT COLLECTOR ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED MAY BE USED FOR THAT PURPOSE. ORDER NO. CA15-002574-3, PUB DATES: 02/12/2016, 02/19/2016, 02/26/2016 CN 18220

SUMMONS (Family Law) CITACION (Derecho familiar) CASE NUMBER (NUMERO DE CASO) DN184188 NOTICE TO RESPONDENT AVISO AL DEMANDADO: Saul Martinez You are being sued. Read the information below and on the next page. Lo han demandando. Lea la informacion a continuacion y en la pagina siguiente. Petitioner’s Name is: Nombre del demandante: Xochitl Martinez You have 30 calendar days after this Summons and Petition are served on you to file a Response (form FL-120 or FL-123) at the court and have a copy served on the petitioner. A letter, phone call, or court appearance will not protect you. If you do not file your Response on time, the court may make orders affecting your marriage or domestic partnership, your property, and custody of your children. You may be ordered to pay support and attorney fees and costs. For legal advice, contact a lawyer immediately. Get help finding a lawyer at the California Courts Online Self-Help Center (www.courts.ca.gov/selfhelp), at the California Legal Services website (www.lawhelpca.org), or by contacting your local county bar association. Tiene 30 dias de calendario despues de haber recibido la entrega legal de esta Citacion y Peticion para presentar una Respuesta (fomulario FL-120 o FL-123) ante la corte y efectuar la entrega legal de una copia al demandante. Una carta o llamada telefonica o una audiencia de la corte no basta para protegerio. Si no presenta su Respuesta a tiempo, la corte puede dar ordenes que afecten su matrimonio o pareja de hecho, sus bienes y la custodia de sus hijos. La corte tambien le puede ordenar que pague manutencion, y honorarios y costos legales. Para asesoramiento legal, pongase en contacto de inmediato con un abogado. Puede abtener informacion para encontrar un abogado en el Centro de Ayuda de las Cortes de California (www.sucorte.ca.gov) en el sitio web de lost Servicios Legales de California (www.lawhelpca.org) o poniendose en contacto con el colegio de abogados de su condado. NOTICE-RESTRAINING ORDERS ARE: These restraining orders are effective against both spouses or domestic partners until the petition is dismissed, a judgment is entered, or the court makes further orders. They are enforceable anywhere in California by any law enforcement officer who has received or seen a copy of them. AVISO-LAS ORDENES DE RESTRICCION: Las ordenes de restriccion estan en vigencia en cuanto a ambos conyuges o miembros de la pareja de hecho hasta que se despida la peticion, se emita un fallo o la corte de otras ordenes. Cualquier agencia del orden publico que haya recibido o visto una copia de estas ordenes puede hacerlas acatar en cualquier lugar de California. FEE WAIVER: If you cannot pay the filing fee, ask the clerk for a fee waiver form. The court may order you to pay back all or part of the fees and costs that the court waived for you or the other party. EXENCION DE CUOTAS: Si no puede pagar la cuota de presentacion, pida al secretario un formulario de exencion de cuotas. La corte puede ordenar que usted pague, ya sea en parte o por completo, las cuotas y costos de la corte previamente exentos a peticion de usted o de la otra parte. The name and address of the court are (El nombre y direccion de la corte son): San Diego Superior Court North County Division 325 S Melrose Dr Vista CA 92081 The name, address, and telephone number of petitioner’s attorney, or petitioner without an attorney, are: (El nombre, direccion y numero de telefono del abogado del demandante, o del demandante si no tiene abogado, son): Xochitl Martinez-Cuevas 1405 Dubuque St Oceanside CA 92058 Telephone: 760.978.1344 Date (Fecha): 08/18/15 Clerk, by (Secretario, por), P. Gomez Deputy (Asistente) NOTICE TO THE PERSON SERVED: You are served as an individual defendant. 02/26, 03/04, 03/11, 03/18/16 CN 18314

ORDER TO SHOW CAUSE FOR CHANGE OF NAME CASE # 37-2016-00005468-CU-PT-NC TO ALL INTERESTED PERSONS: Petitioner(s): Adriana Sanchez filed a petition with this court for a decree changing name as follows: a. Present name: Jonathon Santiago change to proposed name: Jonathon Rendon. THE COURT ORDERS that all persons interested in this matter appear before this Court at the hearing indicated below to show cause, if any, why the petition for a change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. NOTICE OF HEARING: On Apr 5, 2016 at 8:30 a.m., in Dept 26 of the Superior Court of California, 325 S Melrose Dr, Vista CA 92081, North County Regional Division. Date: Feb 19, 2016William S Dato Judge of the Superior Court 02/26, 03/04, 03/11, 03/18/16 CN 18288

ORDER TO SHOW CAUSE FOR CHANGE OF NAME CASE # 37-2016-00005425-CU-PT-NC TO ALL INTERESTED PERSONS: Petitioner(s): Nancy Allen Lindberg filed a petition with this court for a decree changing name as follows: a. Present name: Nancy Allen Lindberg change to proposed name: Nancy Allen Lindbergh. THE COURT ORDERS that all persons interested in this matter appear before this Court at the hearing indicated below to show cause, if any, why the petition for a change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. NOTICE OF HEARING: On Apr 5, 2016 at 8:30 a.m., in Dept 26 of the Superior Court of California, 325 S Melrose Dr, Vista CA 92081, North County Regional Division. Date: Feb 19, 2016 William S Dato Judge of the Superior Court 02/26, 03/04, 03/11, 03/18/16 CN 18287

NOTICE OF PETITION TO ADMINISTER ESTATE OF KATHRYN V SCHMEDDING Case # 37-2015-00034463-PR-LS-CTL To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of Kathryn V. Schmedding. A Petition for Probate has been filed by Connie M. Blair in the Superior Court of California, County of San Diego. The Petition for Probate requests that Connie M. Blair be appointed as personal representative to administer the estate of the decedent. The petition requests the decedent’s will and codicils, if any, be admitted to probate. The will and any codicils are available for examination in the file kept by the court. The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority. A hearing on the petition will be held in this court on Apr 5, 2016 at 11:00 AM in Dept. PC-1 located at 1409 Fourth Ave, San Diego, CA 92101 Madge Bradley Building. If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law. You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk. Attorney for petitioner: Andrea M. Gherini PO Box 2809 Carlsbad CA 92018-2809 Telephone: 760.754.2381 02/26, 03/04, 03/11/16 CN 18286

THE NOTICE OF SALE Notice is herby given that pursuant to Sections 21701-21715 of the Business and Professional Code and Section 2328 of the Commercial Code of California, that Golf Country Mini Storage at 28710 Champagne B l v d, Escondido, CA 92026 will sell property listed below by competitive bidding on or after March 4, 2016. Auction to be held at above address. Property to be sold as follows: misc. items belonging to the following: M. Sofra unit #25 Auction to be con- ducted by: West Coast Auctions Bond #0434194 02/19/16, 02/26/16 CN18256

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON FOR THE COUNTY OF KING ROOSEVELT DEVELOPMENT GROUP, LLC, and TIGER-TWEETUMS, LLC, Plaintiff, vs. MAXINE HAWN, VICKI ELAINE STECKMANN and DIANE MARIE BOYD, the only known heirs to B. Elaine Lansing; the ESTATE OF MARIE NASSEN, the only known heir to Irma H. Bane, and all unknown heirs of MARIE NASSEN; and all other persons or parties unknown claiming any right, title, estate, lien, or interest in the real estate described in the complaint herein, Defendant. No. 16-2-01747-9 SEA The State of Washington to the unknown heirs of the Estate of Marie Nassen: You are hereby summoned to appear within sixty days after the date of the first publication of this summons, to wit, within sixty days after the 19th day of February, 2016, and defend the above entitled action in the above entitled court, and answer the complaint of the plaintiff Roosevelt Development Group, LLC, and Tiger-Tweetums, LLC, and serve a copy of your answer upon the undersigned attorneys for Plaintiff Roosevelt Development Group, LLC, at their attorney’s office below stated; and in case of your failure so to do, judgment will be rendered against you according to the demand of the complaint, which has been filed with the clerk of said court. This is an action to quiet title to certain real property located at 1408 NE 65th St, Seattle, WA 98115. Sean K. Griffee (WSBA #33104) Olivia E. Gonzalez (WSBA #41582) 1420 Fifth Avenue, Suite 3000 Seattle, WA 98101-2393 Telephone: (206) 626-6000 Fax: (206) 464-1496 E-mail: SKG@stokeslaw.com OEG@stokeslaw.com Attorneys for Plaintiff Roosevelt Development Group, LLC 02/19, 02/26, 03/04, 03/11, 03/18, 03/25/16 CN 18255

NOTICE OF PETITION TO ADMINISTER ESTATE OF Theodore D. Griffin Case # 37-2016-00004564-PR-PW-CTL To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of: Theodore D. Griffin. A Petition for Probate has been filed by Adelaide B. Griffin in the Superior Court of California, County of San Diego. The Petition for Probate requests that Adelaide B. Griffin be appointed as personal representative to administer the estate of the decedent. The petition requests the decedent’s will and codicils, if any, be admitted to probate. The will and any codicils are available for examination in the file kept by the court. The petition requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority. A hearing on the petition will be held in this court on Mar 15, 2016 at 11:00 AM in Dept. PC-1 located at 1409 Fourth Ave, San Diego, CA 92101 Madge Bradley Building. If you object to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney. If you are a creditor or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law. You may examine the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk. Attorney for petitioner: Paul V.L. Campo, Esq. 410 S Melrose Dr. #201 Vista CA 92081-6623 Telephone, 760.639.1680 02/19, 02/26, 03/04/16 CN 18254

SUPERIOR COURT OF CALIFORNIA, COUNTY OF SAN DIEGO in re: THE BETTY ANN ROBINSON TRUST AGREEMENT DATED JUNE 6, 1986 BY: Betty Ann Robinson, Decedent NOTICE TO CREDITORS (Cal. Probate Code § 19050) Notice is hereby given to the creditors and contingent creditors of the above-named decedent that all persons having claims against the decedent are required to mail or deliver a copy to Gary Robinson, Trustee of the Betty Ann Robinson Trust Agreement dated June 6, 1986, of which the Decedent was the grantor, c/o BRENDA GEIGER, Attorney at Law, at 1917 Palomar Oaks Way, Suite 160, Carlsbad, CA 92008, within the later of 4 months after date of first publication of notice to creditors or, if notice is mailed or personally delivered to you, 60 days after the date this notice is mailed or personally delivered to you, or you must petition to file a late claim as provided in Probate Code §19103. A claim form may be obtained from the court clerk. For your protection, you are encouraged to file your claim by certified mail, with return receipt requested. Date: February 10, 2016 /s/ BRENDA GEIGER, Attorney at Law Attorney for Trustee, Gary Robinson Pub. … 2016 Geiger Law Office, P.C. 1917 Palomar Oaks Way, Suite 160 Carlsbad, CA 92008 (760) 448-2220 02/19/16, 02/26/16, 03/04/16 CN 18251

ORDER TO SHOW CAUSE FOR CHANGE OF NAME CASE # 37-2016-00003817-CU-PT-CTL TO ALL INTERESTED PERSONS: Petitioner(s): Ann Marie Tran filed a petition with this court for a decree changing names as follows: a. Present name Ann Marie Tran changed to proposed name Ann Marie Koch. THE COURT ORDERS that all persons interested in this matter appear before this Court at the hearing indicated below to show cause, if any, why the petition for a change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. NOTICE OF HEARING: On on Mar 25, 2016 at 8:30 a.m Dept 46 of the Superior Court of California, 220 W Broadway, San Diego CA 92101. Date: Feb 04, 2016 Jeffrey B Barton Judge of the Superior Court 02/12, 02/19, 02/26, 03/04/16 CN 18224

ORDER TO SHOW CAUSE FOR CHANGE OF NAME CASE # 37-2016-00000666-CU-PT-NC TO ALL INTERESTED PERSONS: Petitioner(s): Karen Louise Gleason Huss filed a petition with this court for a decree changing name as follows: a. Present name: Karen Louise Gleason Huss change to proposed name: Karen Gleason Huss (aka: Karen G Huss or Karen Huss). THE COURT ORDERS that all persons interested in this matter appear before this Court at the hearing indicated below to show cause, if any, why the petition for a change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. NOTICE OF HEARING: On May 03, 2016 at 8:30 a.m., in Dept N-26 of the Superior Court of California, 325 S Melrose Dr, Vista CA 92081, North County Regional Division. Date: Jan 11, 2016 William S Dato Judge of the Superior Court 02/12, 02/19, 02/26, 03/04/16 CN 18223

ORDER TO SHOW CAUSE FOR CHANGE OF NAME CASE # 37-2016-00001738-CU-PT-NC TO ALL INTERESTED PERSONS: Petitioner(s): Todd Harold George Jacob Joa filed a petition with this court for a decree changing name as follows: a. Present name: Todd Harold George Jacob Joa change to proposed name: Todd Harold George Jacobs. THE COURT ORDERS that all persons interested in this matter appear before this Court at the hearing indicated below to show cause, if any, why the petition for a change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. NOTICE OF HEARING: On Mar. 08, 2016 at 8:30 a.m., in Dept 26 of the Superior Court of California, 325 S Melrose Dr, Vista CA 92081, North County Regional Division. Date: Jan 20, 2016 William S Dato Judge of the Superior Court 02/05, 02/12, 02/19, 02/26/16 CN 18216

SUMMONS (Family Law) CITACION (Derecho familiar) CASE NUMBER (NUMERO DE CASO) DN183019 NOTICE TO RESPONDENT AVISO AL DEMANDADO: Tae Lee You are being sued. Read the information below and on the next page. Lo han demandando. Lea la informacion a continuacion y en la pagina siguiente. Petitioner’s Name is: Nombre del demandante: Myung Hee Lee You have 30 calendar days after this Summons and Petition are served on you to file a Response (form FL-120 or FL-123) at the court and have a copy served on the petitioner. A letter, phone call, or court appearance will not protect you. If you do not file your Response on time, the court may make orders affecting your marriage or domestic partnership, your property, and custody of your children. You may be ordered to pay support and attorney fees and costs. For legal advise, contact a lawyer immediately. Get help finding a lawyer at the California Courts Online Self-Help Center (www.courts.ca.gov/selfhelp), at the California Legal Services website (www.lawhelpca.org), or by contacting your local county bar association. Tiene 30 dias de calendario despues de haber recibido la entrega legal de esta Citacion y Peticion para presentar una Respuesta (fomulario FL-120 o FL-123) ante la corte y efectuar la entrega legal de una copia al demandante. Una carta o llamada telefonica o una audiencia de la corte no basta para protegerio. Si no presenta su Respuesta a tiempo, la corte puede dar ordenes que afecten su matrimonio o pareja de hecho, sus bienes y la custodia de sus hijos. La corte tambien le puede ordenar que pague manutencion, y honorarios y costos legales. Para asesoramiento legal, pongase en contacto de inmediato con un abogado. Puede abtener informacion para encontrar un abogado en el Centro de Ayuda de las Cortes de California (www.sucorte.ca.gov) en el sitio web de lost Servicios Legales de California (www.lawhelpca.org) o poniendose en contacto con el colegio de abogados de su condado. NOTICE-RESTRAINING ORDERS ARE: These restraining orders are effective against both spouses or domestic partners until the petition is dismissed, a judgment is entered, or the court makes further orders. They are enforceable anywhere in California by any law enforcement officer who has received or seen a copy of them. AVISO-LAS ORDENES DE RESTRICCION: Las ordenes de restriccion estan en vigencia en cuanto a ambos conyuges o miembros de la pareja de hecho hasta que se despida la peticion, se emita un fallo o la corte de otras ordenes. Cualquier agencia del orden publico que haya recibido o visto una copia de estas ordenes puede hacerlas acatar en cualquier lugar de California. FEE WAIVER: If you cannot pay the filing fee, ask the clerk for a fee waiver form. The court may order you to pay back all or part of the fees and costs that the court waived for you or the other party. EXENCION DE CUOTAS: Si no puede pagar la cuota de presentacion, pida al secretario un formulario de exencion de cuotas. La corte puede ordenar que usted pague, ya sea en parte o por completo, las cuotas y costos de la corte previamente exentos a peticion de usted o de la otra parte. The name and address of the court are (El nombre y direccion de la corte son): San Diego Superior Court North County Division 325 S Melrose Dr Vista CA 92081 The name, address, and telephone number of petitioner’s attorney, or petitioner without an attorney, are: (El nombre, direccion y numero de telefono del abogado del demandante, o del demandante si no tiene abogado, son): Myung Hee Lee 17076 Montura Dr San Diego CA 92128 Telephone: 571.318.0340 Date (Fecha): 05/12/15 Clerk, by (Secretario, por), G. McClintic Deputy (Asistente) NOTICE TO THE PERSON SERVED: You are served as an individual defendant. 02/05, 02/12, 02/19, 02/26/16 CN 18213

ORDER TO SHOW CAUSE FOR CHANGE OF NAME CASE # 37-2016-00002962-CU-PT-NC TO ALL INTERESTED PERSONS: Petitioner(s): Kihei Hutchinson filed a petition with this court for a decree changing name as follows: a. Present name: Kihei Emmitt Hutchinson Jr change to proposed name: Kihei Carroll. THE COURT ORDERS that all persons interested in this matter appear before this Court at the hearing indicated below to show cause, if any, why the petition for a change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. NOTICE OF HEARING: On Mar. 15, 2016 at 8:30 a.m., in Dept 26 of the Superior Court of California, 325 S Melrose Dr, Vista CA 92081, North County Regional Division. Date: Jan 29, 2016 William S Dato Judge of the Superior Court 02/05, 02/12, 02/19, 02/26/16 CN 18195

ORDER TO SHOW CAUSE FOR CHANGE OF NAME CASE # 37-2016-00002493-CU-PT-NC TO ALL INTERESTED PERSONS: Petitioner(s): John Robert Creighton Jr filed a petition with this court for a decree changing name as follows: a. Present name: John Robert Creighton Jr change to proposed name: John Robert Theuber. THE COURT ORDERS that all persons interested in this matter appear before this Court at the hearing indicated below to show cause, if any, why the petition for a change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing.NOTICE OF HEARING: On Mar. 15, 2016 at 8:30 a.m., in Dept 26 of the Superior Court of California, 325 S Melrose Dr, Vista CA 92081, North County Regional Division. Date: Jan 26, 2016 William S Dato Judge of the Superior Court 02/05, 02/12, 02/19, 02/26/16 CN 18194

ORDER TO SHOW CAUSE FOR CHANGE OF NAME CASE # 37-2016-00002534-CU-PT-NC TO ALL INTERESTED PERSONS: Petitioner(s): Sohaila Atiq and Aziz Atiq filed a petition with this court for a decree changing name on behalf of minor children as follows: a. Present name: Hejran H. Atiq change to proposed name: Aaron H. Atiq; b. Present name: Khyber Atiq change to proposed name: Kai K. Atiq. THE COURT ORDERS that all persons interested in this matter appear before this Court at the hearing indicated below to show cause, if any, why the petition for a change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. NOTICE OF HEARING: On Mar. 15, 2016 at 8:30 a.m., in Dept 26 of the Superior Court of California, 325 S Melrose Dr, Vista CA 92081, North County Regional Division. Date: Jan 26, 2016 William S Dato Judge of the Superior Court 02/05, 02/12, 02/19, 02/26/16 CN 18193

Fictitious Business Name Statement #2016-004531 Filed: Feb 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. BBH & Associates, Located at: 3879 Stoneridge Rd, Carlsbad CA San Diego 92010 Mailing Address: 300 Carlsbad Village Dr Ste 108A #366, Carlsbad CA 92008 This business is hereby registered by the following: 1. BBH & Associates, 3879 Stoneridge Rd, Carlsbad CA 92010 This business is conducted by: A Limited Liability Company The first day of business was: 12/17/10 S/Shane T Allen, 02/26, 03/04, 03/11, 03/18/16 CN 18313

Fictitious Business Name Statement #2016-002659 Filed: Jan 29, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Patchouli Baby, Located at: 429-A S Freeman St, Oceanside CA San Diego 92054 Mailing Address: Same This business is hereby registered by the following: 1. Rene Rosman, 429-A S Freeman St, Oceanside CA 92054 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Rene Rosman, 02/26, 03/04, 03/11, 03/18/16 CN 18308

Fictitious Business Name Statement #2016-004903 Filed: Feb 22, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Doce Chocolate Balls, Located at: 3360 Avenida Nieve, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Linda Friz, 3360 Avenida Nieve, Carlsbad CA 92009 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Linda Friz, 02/26, 03/04, 03/11, 03/18/16 CN 18307

Fictitious Business Name Statement #2016-004610 Filed: Feb 18, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Chrissy Walther Photography; B. Chrissy W. Photo, Located at: 198 Evvia Ct, Vista CA San Diego 92083 Mailing Address: Same This business is hereby registered by the following: 1. Christine Walther, 198 Evvia Ct, Vista CA 92083 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Christine Walther, 02/26, 03/04, 03/11, 03/18/16 CN 18306

Fictitious Business Name Statement #2016-004605 Filed: Feb 18, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Adam’s Maintenance, Located at: 3043 Bernardo Ave, Escondido CA San Diego 92029 Mailing Address: Same This business is hereby registered by the following: 1. Adam Kirby, 3043 Bernardo Ave, Escondido CA 92029 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Adam Kirby, 02/26, 03/04, 03/11, 03/18/16 CN 18305

Fictitious Business Name Statement #2016-004427 Filed: Feb 16, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Village Family Yoga, Located at: 1164 Quail Gardens Ct, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Theresa Bergdahl, 1164 Quail Gardens Ct, Encinitas CA 92024; 2. Andrew Bergdahl, 1164 Quail Gardens Ct, Encinitas CA 92024 This business is conducted by: A Married Couple The first day of business was: Not Yet Started S/Theresa Bergdahl, 02/26, 03/04, 03/11, 03/18/16 CN 18303

Fictitious Business Name Statement #2016-004511 Filed: Feb 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Unleashed Potential, Located at: 1832 Corte Amarillo, Oceanside CA San Diego 92056 Mailing Address: Same This business is hereby registered by the following: 1. Mary Kay Snyder, 1832 Corte Amarillo, Oceanside CA 92056 This business is conducted by: An Individual The first day of business was: 10/01/15 S/Mary Kay Snyder, 02/26, 03/04, 03/11, 03/18/16 CN 18302

Fictitious Business Name Statement #2016-004458 Filed: Feb 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Truly Kneaded, Located at: 2417 Aqua Hill Rd, Fallbrook CA San Diego 92028 Mailing Address: Same This business is hereby registered by the following: 1. Catherine Eckert, 2417 Aqua Hill Rd, Fallbrook CA 92028 This business is conducted by: An Individual The first day of business was: 01/02/16 S/Catherine L Eckert, 02/26, 03/04, 03/11, 03/18/16 CN 18301

Fictitious Business Name Statement #2016-004486 Filed: Feb 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. That Help Guy, Located at: 3747 Vista Campana S #77, Oceanside CA San Diego 92057 Mailing Address: Same This business is hereby registered by the following: 1. Dennis deFarcy, 3747 Vista Campana S #77, Oceanside CA 92057 This business is conducted by: An Individual The first day of business was: 02/13/16 S/Dennis deFarcy, 02/26, 03/04, 03/11, 03/18/16 CN 18300

Fictitious Business Name Statement #2016-004023 Filed: Feb 11, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. TPC HR/Payroll Consultants, Located at: 3129 Tiger Run Ct #219, Carlsbad CA San Diego 92010 Mailing Address: Same This business is hereby registered by the following: 1. Poseidon Consultants Inc, 3129 Tiger Run Ct #219, Carlsbad CA 92010 This business is conducted by: A Corporation The first day of business was: 05/17/10 S/Michael Taff, 02/26, 03/04, 03/11, 03/18/16 CN 18299

Fictitious Business Name Statement #2016-004585 Filed: Feb 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Teaspoon Treats, Located at: 1047 Golden Rd #C, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Jennifer Whiting, 1047 Golden Rd #C, Encinitas CA 92024 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Jennifer Whiting, 02/26, 03/04, 03/11, 03/18/16 CN 18298

Fictitious Business Name Statement #2016-004807 Filed: Feb 19, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Symbol Real Estate, Located at: 332 Encinitas Blvd #100, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Symbol Real Estate SB Inc, 332 Encinitas Blvd #100, Encinitas CA 92024 This business is conducted by: A Corporation The first day of business was: Not Yet Started S/Ryan Ponsford, 02/26, 03/04, 03/11, 03/18/16 CN 18297

Fictitious Business Name Statement #2016-003654 Filed: Feb 08, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Stellar Elite Auto Detail; B. Stellar Auto Detail, Located at: 351 Sprucewood Dr, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Ronald Rey, 351 Sprucewood Dr, Encinitas CA 92024 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Ronald Rey, 02/26, 03/04, 03/11, 03/18/16 CN 18296

Fictitious Business Name Statement #2016-002988 Filed: Feb 02, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Rapidserv Inc, Located at: 2514 Via Naranja, Carlsbad CA San Diego 92010 Mailing Address: PO Box 4172, Carlsbad CA 92018 This business is hereby registered by the following: 1. Rapidserv Inc, 2514 Via Naranja, Carlsbad CA 92010 This business is conducted by: A Corporation The first day of business was: 03/08/09 S/Sheldon Homa, 02/26, 03/04, 03/11, 03/18/16 CN 18295

Fictitious Business Name Statement #2016-004349 Filed: Feb 16, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Lifegate Community Church, Located at: 7815 Quebrada Circle, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Lifegate Community Church Inc, 7815 Quebrada Circle, Carlsbad CA 92009 This business is conducted by: A Corporation The first day of business was: 06/28/03 S/William A Burkhardt, 02/26, 03/04, 03/11, 03/18/16 CN 18294

Fictitious Business Name Statement #2016-004452 Filed: Feb 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. La Isia Neveria, Located at: 327 S Rancho Santa Fe Rd #B, San Marcos CA San Diego 92078 Mailing Address: 3823 Commodore Dr, San Marcos CA 92078 This business is hereby registered by the following: 1. David De La Cruz, 3823 Commodore Dr, San Marcos CA 92078 This business is conducted by: An Individual The first day of business was: Not Yet Started S/David De La Cruz, 02/26, 03/04, 03/11, 03/18/16 CN 18293

Fictitious Business Name Statement #2016-004748 Filed: Feb 19, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Healthy Habits Hypnosis; B. Mind Body Health Publishing, Located at: 187 Calle Magdalena #216, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Jill Thomas, 1315 Condor Ct, Encinitas CA 92024 This business is conducted by: An Individual The first day of business was: 06/08/08 S/Jill Thomas, 02/26, 03/04, 03/11, 03/18/16 CN 18292

Fictitious Business Name Statement #2016-003563 Filed: Feb 05, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Grandview Funding and Properties, Located at: 20461 Elfin Forest Rd, Escondido CA San Diego 92029 Mailing Address: Same This business is hereby registered by the following: 1. Scott Schroeder, 20461 Elfin Forest Rd, Escondido CA 92029 This business is conducted by: An Individual The first day of business was: 01/06/16 S/Scott Schroeder, 02/26, 03/04, 03/11, 03/18/16 CN 18291

Fictitious Business Name Statement #2016-004187 Filed: Feb 12, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Genesis California; B. Genesis; C. Genesis Energy Solutions, Located at: 1904 S Horne St, Oceanside CA San Diego 92054 Mailing Address: Same This business is hereby registered by the following: 1. Jesse Freund, 1044 Sunset Dr, Vista CA 92081; 2. David Freund, 1904 S Horne St, Oceanside CA 92054; 3. Jordan Manley, N7031. Mount Carrol St, Dalton Gardens ID 83815 This business is conducted by: A General Partnership The first day of business was: 01/01/12 S/Jesse Freund, 02/26, 03/04, 03/11, 03/18/16 CN 18290

Fictitious Business Name Statement #2016-004454 Filed: Feb 17, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Bulldog Development, General Contractor, Located at: 1582 Windsor Rd, Cardiff CA San Diego 92007 Mailing Address: Same This business is hereby registered by the following: 1. Michael B Tice, 1582 Windsor Rd, Cardiff CA 92007 This business is conducted by: An Individual The first day of business was: 07/01/85 S/Michael B Tice, 02/26, 03/04, 03/11, 03/18/16 CN 18289

Fictitious Business Name Statement #2016-004361 Filed: Feb 16, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. CloRey Concepts; B. BumperTops, Located at: 7733 Palacio Dr, Carlsbad CA San Diego 92009 Mailing Address: PO Box 235355, Encinitas CA 92023 This business is hereby registered by the following: 1. Gary Clough, 7733 Palacio Dr, Carlsbad CA 92009; 2. Keith Reynolds, 2111 Placido Ct, Carlsbad CA 92009 This business is conducted by: A General Partnership The first day of business was: Not Yet Started S/Gary Clough, 02/19, 02/26, 03/04, 03/11/16 CN 18275

Fictitious Business Name Statement #2016-003220 Filed: Feb 04, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Cavanaugh Real Estate Group; B. Cavanaugh Property Management, Located at: 2130 Redwood Crest, Vista CA San Diego 92081 Mailing Address: Same This business is hereby registered by the following: 1. Cavanaugh Properties Inc, 2130 Redwood Crest, Vista CA 92081 This business is conducted by: A Corporation The first day of business was: 01/02/16 S/Caleb McKinley, 02/19, 02/26, 03/04, 03/11/16 CN 18274

Fictitious Business Name Statement #2016-003329 Filed: Feb 04, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Traction; B. Wander and Perch; C. Wander Wet Bags; D. Horizon Collaborative; Life Monarch, Located at: 1848 Avenida Mimosa, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Eileen Zimmerman, 1848 Avenida Mimosa, Encinitas CA 92024; 2. Sean Zimmerman, 1848 Avenida Mimosa, Encinitas CA 92024 This business is conducted by: A Married Couple The first day of business was: 01/01/16 S/Eileen Zimmerman, 02/19, 02/26, 03/04, 03/11/16 CN 18273

Fictitious Business Name Statement #2016-003190 Filed: Feb 04, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Sugarbird Studio, Located at: 1623 N Vulcan Ave, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Erin Brimmer, 1623 N Vulcan Ave, Encinitas CA 92024 This business is conducted by: An Individual The first day of business was: 06/18/13 S/Erin Brimmer, 02/19, 02/26, 03/04, 03/11/16 CN 18272

Fictitious Business Name Statement #2016-004004 Filed: Feb 11, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Structure-Creative Services Consulting, Located at: 2829 Carrillo Way, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Joni Reeves, 2829 Carrillo Way, Carlsbad CA 92009 This business is conducted by: An Individual The first day of business was: 01/04/16 S/Joni Reeves, 02/19, 02/26, 03/04, 03/11/16 CN 18271

Fictitious Business Name Statement #2016-004129 Filed: Feb 12, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Put on Love Designs, Located at: 1542 Del Mar Rd #2, Oceanside CA San Diego 92057 Mailing Address: Same This business is hereby registered by the following: 1. Chelsea Tenney, 1542 Del Mar Rd #2, Oceanside CA 92057 This business is conducted by: An Individual The first day of business was: 01/01/16 S/Chelsea Tenney, 02/19, 02/26, 03/04, 03/11/16 CN 18270

Fictitious Business Name Statement #2016-002675 Filed: Jan 29, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. LCG Graphix, Located at: 1146 Country Wood Ln, Vista CA San Diego 92081 Mailing Address: Same This business is hereby registered by the following: 1. 007 Enterprises Inc, 1146 Country Wood Ln, Vista CA 92081 This business is conducted by: A Limited Liability Company The first day of business was: 08/01/15 S/Sean De Gruchy, 02/19, 02/26, 03/04, 03/11/16 CN 18269

Fictitious Business Name Statement #2016-003987 Filed: Feb 11, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Healing Circus, Located at: 1017 Hygeia Ave, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Jodi Harary, 1017 Hygeia Ave, Encinitas CA 92024 This business is conducted by: An Individual The first day of business was: 02/09/16 S/Jodi Harary, 02/19, 02/26, 03/04, 03/11/16 CN 18268

Fictitious Business Name Statement #2016-003199 Filed: Feb 04, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Horace Anderson Greenhouses LLC; B. Horace Anderson; C. Anderson Growers; D. H. Anderson; E. Greenhouse by the Sea, Located at: 375 La Costa Ave, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Horace Anderson Greenhouses LLC, 375 La Costa Ave, Encinitas CA 92024 This business is conducted by: A Limited Liability Company The first day of business was: 01/01/14 S/Ben M Hofstetter, 02/19, 02/26, 03/04, 03/11/16 CN 18267

Fictitious Business Name Statement #2016-004009 Filed: Feb 11, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. GTUBRIT, Located at: 3466 Corte Sonrisa, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Jacqueline J Corney, 3466 Corte Sonrisa, Carlsbad CA 92009 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Jacqueline J Corney, 02/19, 02/26, 03/04, 03/11/16 CN 18266

Fictitious Business Name Statement #2016-004019 Filed: Feb 11, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. County Inspector Services, Located at: 1633 S Myers #1, Oceanside CA San Diego 92054 Mailing Address: Same This business is hereby registered by the following: 1. Steven T Bugiel, 1633 S Myers #1, Oceanside CA 92054 This business is conducted by: An Individual The first day of business was: 01/01/16 S/Steven T Bugiel, 02/19, 02/26, 03/04, 03/11/16 CN 18265

Fictitious Business Name Statement #2016-001980 Filed: Jan 25, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Coastal Costing, Located at: 4645 Mystik Rd, Oceanside CA San Diego 92056 Mailing Address: Same This business is hereby registered by the following: 1. Paul Iezzi, 4645 Mystik Rd, Oceanside CA 92056 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Paul Iezzi, 02/19, 02/26, 03/04, 03/11/16 CN 18264

Fictitious Business Name Statement #2016-002788 Filed: Feb 01, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Clear Water Pools, B. Clear Water Pools Service & Repair, Located at: 150 Cherry Ave, Carlsbad CA San Diego 92008 Mailing Address: PO Box 1112, Carlsbad CA 92018 This business is hereby registered by the following: 1. Mark Carruth, 150 Cherry Ave, Carlsbad CA 92008 This business is conducted by: An Individual The first day of business was: 02/01/16 S/Mark Carruth, 02/19, 02/26, 03/04, 03/11/16 CN 18263

Fictitious Business Name Statement #2016-003776 Filed: Feb 09, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Chicweed Design & Landscaping LLC, Located at: 7047 Zubaron Ln, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Chicweed Design & Landscaping LLC, 7047 Zubaron Ln, Carlsbad CA 92009 This business is conducted by: A Limited Liability Company The first day of business was: 01/30/16 S/Melissa Teisl, 02/19, 02/26, 03/04, 03/11/16 CN 18262

Fictitious Business Name Statement #2016-002527 Filed: Jan 28, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Audi Carlsbad, Located at: 5425 Paseo del Norte, Carsbad CA San Diego 92008 Mailing Address: PO Box 789, Carlsbad CA 92018 This business is hereby registered by the following: 1. Hoehn Motors Inc, 5475 Car Country Dr, Carlsbad CA 92008 This business is conducted by: A Corporation The first day of business was: Not Yet Started S/Gloria Rediker, 02/19, 02/26, 03/04, 03/11/16 CN 18261

Fictitious Business Name Statement #2016-001965 Filed: Jan 22, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Apex Training Center; B. Apex Muay Thai, Located at: 1832 Ord Way, Oceanside CA San Diego 92056 Mailing Address: 2020 Felicita Rd, Escondido CA 92025 This business is hereby registered by the following: 1. Apex Training Center LLC, 2020 Felicita Rd, Escondido CA 92025 This business is conducted by: A Limited Liability Company The first day of business was: Not Yet Started S/Ed Buckley, 02/19, 02/26, 03/04, 03/11/16 CN 18260

Fictitious Business Name Statement #2016-002454 Filed: Jan 28, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Anchoredman Ministries, Located at: 3510 Lone Pine Ln, San Marcos CA San Diego 92078 Mailing Address: Same This business is hereby registered by the following: 1. Jason Graves, 3510 Lone Pine Ln, San Marcos CA 92078 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Jason Graves, 02/19, 02/26, 03/04, 03/11/16 CN 18259

Fictitious Business Name Statement #2016-004005 Filed: Feb 11, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. 7 Day Weekend, Located at: 2635 Madison St #27, Carlsbad CA San Diego 92008 Mailing Address: Same This business is hereby registered by the following: 1. Steven Randolph, 2635 Madison St #27, Carlsbad CA 92008 This business is conducted by: An Individual The first day of business was: 01/01/16 S/Steven Randolph, 02/19, 02/26, 03/04, 03/11/16 CN 18258

Fictitious Business Name Statement #2016-003514 Filed: Feb 05, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Carpet Quest, Located at: 1945 S Rancho Sante Fe Rd #A, San Marcos CA San Diego 92078 Mailing Address: Same This business is hereby registered by the following: 1. Dennis Herald, 3017 Azahar Ct, Carlsbad CA 92009 This business is conducted by: An Individual The first day of business was: 03/01/83 S/Dennis Herald, 02/12, 02/19, 02/26, 03/04/16 CN 18247

Fictitious Business Name Statement #2016-003569 Filed: Feb 05, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Z Bee Delivery, Located at: 1354 Greenway Rise, Escondido CA San Diego 92027 Mailing Address: Same This business is hereby registered by the following: 1. Shannon Chairez, 1354 Greenway Rise, Escondido CA 92027 2. Andy Chairez, 1354 Greenway Rise, Escondido CA 92027 This business is conducted by: A Married Couple The first day of business was: Not Yet Started S/Shannon Chairez, 02/12, 02/19, 02/26, 03/04/16 CN 18246

Fictitious Business Name Statement #2016-003510 Filed: Feb 05, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Torrey Pines Brewing, Located at: 13754 Mango Dr #302, Del Mar CA San Diego 92014 Mailing Address: Same This business is hereby registered by the following: 1. Eric Strate, 13754 Mango Dr #302, Del Mar CA 92014 2. Kayla Strate, 13754 Mango Dr #302, Del Mar CA 92014 This business is conducted by: A Married Couple The first day of business was: Not Yet Started S/Eric Strate, 02/12, 02/19, 02/26, 03/04/16 CN 18245

Fictitious Business Name Statement #2015-032401 Filed: Dec 18, 2015, Second Notary dated: Feb 03, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. TNT Cable Industries, Located at: 350 Mulberry Dr, San Marcos CA San Diego 92069 Mailing Address: Same This business is hereby registered by the following: 1. TNT Assembly LLC, 350 Mulberry Dr, San Marcos CA 92069 This business is conducted by: A Limited Liability Company The first day of business was: 12/01/15 S/Carlos Navarro, 02/12, 02/19, 02/26, 03/04/16 CN 18244

Fictitious Business Name Statement #2016-002567 Filed: Jan 29, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Solar Eclipse B. Tint Works, Located at: 1351 Marquette St #A, Oceanside CA San Diego 92058 Mailing Address: Same This business is hereby registered by the following: 1. Ashton Rybicki, 1351 Marquette St #A, Oceanside CA 92058 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Ashton Rybicki, 02/12, 02/19, 02/26, 03/04/16 CN 18243

Fictitious Business Name Statement #2016-002873 Filed: Feb 02, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Sweet Peas Signing, Located at: 1030 Stephanie Ct #109, San Marcos CA San Diego 92078 Mailing Address: Same This business is hereby registered by the following: 1. Nicole Sedano, 1030 Stephanie Ct #109, San Marcos CA 92078 This business is conducted by: An Individual The first day of business was: 01/09/16 S/Nicole Sedano, 02/12, 02/19, 02/26, 03/04/16 CN 18242

Fictitious Business Name Statement #2016-003727 Filed: Feb 09, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Station Salon B. L-Line Hair Stop, Located at: 345 S Coast Hwy 101, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Osinga Inc, 366 N Sierra Ave, Solana Beach CA 92075 This business is conducted by: A Corporation The first day of business was: 02/09/16 S/Dana Osinga, 02/12, 02/19, 02/26, 03/04/16 CN 18241

Fictitious Business Name Statement #2016-003679 Filed: Feb 08, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Nightmare Armory, Located at: 5170 Prado Ct, Oceanside CA San Diego 92057 Mailing Address: Same This business is hereby registered by the following: 1. George Dellinger, 5170 Prado Ct, Oceanside CA 92057 This business is conducted by: An Individual The first day of business was: Not Yet Started S/George Dellinger, 02/12, 02/19, 02/26, 03/04/16 CN 18240

Fictitious Business Name Statement #2016-001315 Filed: Jan 15, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. H Q P, Located at: 2680 Alameda Circle, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Seung Ho Baek, 2680 Alameda Circle, Carlsbad CA 92009 This business is conducted by: An Individual The first day of business was: 01/15/16 S/Seung Ho Baek, 02/12, 02/19, 02/26, 03/04/16 CN 18239

Fictitious Business Name Statement #2016-002990 Filed: Feb 02, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. The Paladin Group, Located at: 3576 Binnacle Way, Oceanside CA San Diego 92054 Mailing Address: Same This business is hereby registered by the following: 1. William J McNeese, 3576 Binnacle Way, Oceanside CA 92054 This business is conducted by: An Individual The first day of business was: 02/01/16 S/William J McNeese, 02/12, 02/19, 02/26, 03/04/16 CN 18233

Fictitious Business Name Statement #2016-002693 Filed: Jan 29, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. The Doorkeeper, Located at: 1613 Encino Dr, Escondido CA San Diego 92025 Mailing Address: Same This business is hereby registered by the following: 1. Jeremiah Stock, 1613 Encino Dr, Escondido CA 92025 This business is conducted by: An Individual The first day of business was: 05/04/04 S/Jeremiah Stock, 02/12, 02/19, 02/26, 03/04/16 CN 18232

Fictitious Business Name Statement #2016-003078 Filed: Feb 03, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Sirona’s Cauldron, Located at: 3152 Avenida Alcor, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Christina Wilkerson, 3152 Avenida Alcor, Carlsbad CA 92009 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Christina Wilkerson, 02/12, 02/19, 02/26, 03/04/16 CN 18231

Fictitious Business Name Statement #2016-001125 Filed: Jan 14, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Mar Y Lana; B. Mar Y Lana Shop, Located at: 1254 Orkney Ln, Cardiff CA San Diego 92007 Mailing Address: Same This business is hereby registered by the following: 1. Johanna Swanson, 1254 Orkney Ln, Cardiff CA 92007 This business is conducted by: An Individual The first day of business was: 12/09/15 S/Johanna Swanson, 02/12, 02/19, 02/26, 03/04/16 CN 18230

Fictitious Business Name Statement #2016-002209 Filed: Jan 26, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Laurite Consulting; B. The Painted Arch, Located at: 2354 Alta Vista Dr, Vista CA San Diego 92084 Mailing Address: 1611-A S Melrose Dr #514, Vista CA 92081 This business is hereby registered by the following: 1. Laura Vass, 2354 Alta Vista Dr, Vista CA 92084 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Laura Vass, 02/12, 02/19, 02/26, 03/04/16 CN 18229

Fictitious Business Name Statement #2016-002931 Filed: Feb 02, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Hinrichs Electric, Located at: 141 Oceanview Dr, Vista CA San Diego 92084 Mailing Address: Same This business is hereby registered by the following: 1. Joel Hinrichs, 141 Oceanview Dr, Vista CA 92084 This business is conducted by: An Individual The first day of business was: 12/17/07 S/Joel Hinrichs, 02/12, 02/19, 02/26, 03/04/16 CN 18228

Fictitious Business Name Statement #2016-003161 Filed: Feb 04, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Esperti Print Solutions; B. Esperti Design, Located at: 2381 Newport Ave, Cardiff CA San Diego 92007 Mailing Address: Same This business is hereby registered by the following: 1. Robert V Esperti, 2381 Newport Ave, Cardiff CA 92007 This business is conducted by: An Individual The first day of business was: 01/01/16 S/Robert V Esperti, 02/12, 02/19, 02/26, 03/04/16 CN 18227

Fictitious Business Name Statement #2016-002694 Filed: Jan 29, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Doorkeeper Inc, Located at: 1613 Encino Dr, Escondido CA San Diego 92025 Mailing Address: Same This business is hereby registered by the following: 1. Doorkeeper Inc, 1613 Encino Dr, Escondido CA 92025 This business is conducted by: A Corporation The first day of business was: 06/01/14 S/Jeremiah Stock, 02/12, 02/19, 02/26, 03/04/16 CN 18226

Fictitious Business Name Statement #2016-002921 Filed: Feb 02, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Best Rock Products, Located at: 990 Highland Dr #212, Solana Beach CA San Diego 92075 Mailing Address: PO Box 1450, Solana Beach CA 92075 This business is hereby registered by the following: 1. Jack D Nickolaisen, 990 Highland Dr #212, Solana Beach CA 92075 This business is conducted by: An Individual The first day of business was: 02/01/16 S/Jack D Nickolaisen, 02/12, 02/19, 02/26, 03/04/16 CN 18225

Fictitious Business Name Statement #2016-002424 Filed: Jan 28, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Steelrock Roof Products;
B. Ram Supply Co; C. Metro Roof Products; D. Ram Metal Roof Mart, Located at: 3093-A Industry St, Oceanside CA San Diego 92054 Mailing Address: 10701 S River Front Pkwy #300, South Jordan, UT 84095 This business is hereby registered by the following: 1. Metrotile Manufacturing LLC, 10701 S River Front Pkwy #300, South Jordan, UT 84095 This business is conducted by: A Limited Liability Company The first day of business was: 11/13/15 S/Michael R Mildenhall, 02/05, 02/12, 02/19, 02/26/16 CN 18218

Fictitious Business Name Statement #2016-002222 Filed: Jan 26, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Julie Mack & Associates, Located at: 380 Stevens Ave #310, Solana Beach CA San Diego 92075 Mailing Address: Same This business is hereby registered by the following: 1. Julie R Mack, APC, 380 Stevens Ave #310, Solana Beach CA 92075 This business is conducted by: A Corporation The first day of business was: 01/01/16 S/Julie Mack, 02/05, 02/12, 02/19, 02/26/16 CN 18217

Fictitious Business Name Statement #2016-002074 Filed: Jan 25, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Yoga Oceanside, Located at: 1830-E Oceanside Blvd, Oceanside CA San Diego 92054 Mailing Address: Same This business is hereby registered by the following: 1. Living Aloha LLC, 4640 Admiralty Way #500, Marina del Rey CA 90292 2. True Nature LLC, 603 Seagaze Dr #424, Oceanside CA 92054 This business is conducted by: A General Partnership The first day of business was: 11/02/09 S/Danielle Fowler, 02/05, 02/12, 02/19, 02/26/16 CN 18212

Fictitious Business Name Statement #2016-000481 Filed: Jan 07, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Wild Poppy, B. The Wild Poppy, C. Poppy Clothing Boutique, Located at: 282A N El Camino Real, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Spin Again LLC, 339 N El Camino Real, Encinitas CA 92024 This business is conducted by: A Limited Liability Company The first day of business was: 01/01/16 S/Wendy Goad, 02/05, 02/12, 02/19, 02/26/16 CN 18211

Fictitious Business Name Statement #2016-001667 Filed: Jan 20, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Tea and Empathy Counseling, Located at: 2210 Encinitas Blvd #T, Encinitas CA San Diego 92024 Mailing Address: 174 Andrew Ave, Leucadia CA 92024 This business is hereby registered by the following: 1. Nicola Ranson, 174 Andrew Ave, Leucadia CA 92024 This business is conducted by: An Individual The first day of business was: 10/20/04 S/Nicola Ranson, 02/05, 02/12, 02/19, 02/26/16 CN 18209

Fictitious Business Name Statement #2016-002485 Filed: Jan 28, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Smarter Small Business B. Do Business Smarter, Located at: 2382 Faraday #250, Carlsbad CA San Diego 92008 Mailing Address: 2872 Brandeis Dr, Oceanside CA 92056 This business is hereby registered by the following: 1. Colm Kelly, 2872 Brandeis Dr, Oceanside CA 92056 2. Brena Kelly, 2872 Brandeis Dr, Oceanside CA 92056 This business is conducted by: A Married Couple The first day of business was: 02/01/16 S/Brena Kelly, 02/05, 02/12, 02/19, 02/26/16 CN 18208

Fictitious Business Name Statement #2016-002797 Filed: Feb 01, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Santosha Life, B. Santosha Life School of Yoga, Located at: 1316 Woodhaven Dr, Oceanside CA San Diego 92056 Mailing Address: Same This business is hereby registered by the following: 1. Anusheh Chavez, 1316 Woodhaven Dr, Oceanside CA 92056 B. Mike Forgione, 1316 Woodhaven Dr, Oceanside CA 92056 This business is conducted by: A General Partnership The first day of business was: 02/01/16 S/Anusheh Chavez, 02/05, 02/12, 02/19, 02/26/16 CN 18207

Fictitious Business Name Statement #2016-002390 Filed: Jan 27, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Prove It Fit, Located at: 2814 Avenida Valera, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Louis Hunt, 2814 Avenida Valera, Carlsbad CA 92009 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Louis Hunt, 02/05, 02/12, 02/19, 02/26/16 CN 18206

Fictitious Business Name Statement #2016-002385 Filed: Jan 27, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Plaza del Oro Cleaners Inc, Located at: 4140 Oceanside #149, Oceanside CA San Diego 92056 Mailing Address: Same This business is hereby registered by the following: 1. Plaza del Oro Cleaners Inc, 4140 Oceanside #149, Oceanside CA 92056 This business is conducted by: A Corporation The first day of business was: 09/06/96 S/Ki Sung Choi, 02/05, 02/12, 02/19, 02/26/16 CN 18205

Fictitious Business Name Statement #2016-002070 Filed: Jan 25, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Olivia Grace, Located at: 1497 Crystal Ct, San Marcos CA San Diego 92078 Mailing Address: Same This business is hereby registered by the following: 1. Judith Jones, 1497 Crystal Ct, San Marcos CA 92078 This business is conducted by: An Individual The first day of business was: 03/18/14 S/Judith Jones, 02/05, 02/12, 02/19, 02/26/16 CN 18204

Fictitious Business Name Statement #2016-002474 Filed: Jan 28, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. North County School of the Arts, Located at: 287 Countryhaven Rd, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Scott Gregory, 287 Countryhaven Rd, Encinitas CA 92024 2. Pamela Laurent, 287 Countryhaven Rd, Encinitas CA 92024 This business is conducted by: A Married Couple The first day of business was: 09/01/97 S/Scott Gregory, 02/05, 02/12, 02/19, 02/26/16 CN 18203

Fictitious Business Name Statement #2016-002204 Filed: Jan 26, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Impossible Circus, Located at: 747 Bel Air Drive West, Vista CA San Diego 92084 Mailing Address: Same This business is hereby registered by the following: 1. David Poznanter, 747 Bel Air Drive West, Vista CA 92084, 2. Peter Adeney, 1636 Ocean View Ave, Kensington CA 94707 This business is conducted by: Co-Partners The first day of business was: 01/01/16 S/Paul Poznanter, 02/05, 02/12, 02/19, 02/26/16 CN 18202

Fictitious Business Name Statement #2016-002208 Filed: Jan 26, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Homegrown Maps, Located at: 657 Poinsettia Park S, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Mettja Kuna, 657 Poinsettia Park S., Encinitas CA 92024 2. Bradley Kuna, 657 Poinsettia Park S., Encinitas CA 92024 This business is conducted by: A Married Couple The first day of business was: Not Yet Started S/Mettja Kuna, 02/05, 02/12, 02/19, 02/26/16 CN 18201

Fictitious Business Name Statement #2016-002541 Filed: Jan 28, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Design Art Museum, Located at: 523 N Acacia Ave, Solana Beach CA San Diego 92075 Mailing Address: Same This business is hereby registered by the following: 1. Pia V. White, 523 N Acacia Ave, Solana Beach CA 92075 B. Alexandra M. Roocroft, 523 N Acacia Ave, Solana Beach CA 92075 This business is conducted by: A General Partnership The first day of business was: Not Yet Started S/Pia V. White, 02/05, 02/12, 02/19, 02/26/16 CN 18200

Fictitious Business Name Statement #2016-002240 Filed: Jan 26, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. CraftEd Curriculum, Located at: 1928 Park Crest Dr, Cardiff CA San Diego 92007 Mailing Address: Same This business is hereby registered by the following: 1. Jennifer Pieratt, 1928 Park Crest Dr, Cardiff CA 92007 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Jennifer Pieratt, 02/05, 02/12, 02/19, 02/26/16 CN 18199

Fictitious Business Name Statement #2016-002346 Filed: Jan 27, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. The Bateman Team, Located at: 2824 Hutchinson St, Vista CA San Diego 92084 Mailing Address: Same This business is hereby registered by the following: 1. Erika Bateman, 2824 Hutchison St, Vista CA 92084 2. Alan Bateman, 2824 Hutchison St, Vista CA 92084 This business is conducted by: A Married Couple The first day of business was: 01/27/16 S/Erika Bateman, 02/05, 02/12, 02/19, 02/26/16 CN 18198

Fictitious Business Name Statement #2016-002494 Filed: Jan 28, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Arnibah Vanst Wholesale, Located at: 2625 Pirineos Way #217, Carlsbad CA San Diego 92009 Mailing Address: Same This business is hereby registered by the following: 1. Arnibah Vanst, 2625 Pirineos Way, Carlsbad CA 92009 This business is conducted by: An Individual The first day of business was: Not Yet Started S/Arnibah Vanst, 02/05, 02/12, 02/19, 02/26/16 CN 18197

Fictitious Business Name Statement #2016-002795 Filed: Feb 01, 2016 with County of the San Diego Recorder/County Clerk. Fictitious Business Name(s): A. Activate; B. Meraki; C. You Plus Me; D. R3 Films; E. Rec Ready Recording, Located at: 1060 Arcadia Rd, Encinitas CA San Diego 92024 Mailing Address: Same This business is hereby registered by the following: 1. Sofia Ortiz, 1060 Arcadia Rd, Encinitas CA 92024, 2. Edmont M. Ortiz, 1060 Arcadia Rd, Encinitas CA 92024 This business is conducted by: A Married Couple The first day of business was: 12/22/10 S/Sofia Ortiz, 02/05, 02/12, 02/19, 02/26/16 CN 18196

0 Comments

Leave a reply

Your email address will not be published. Required fields are marked *

*

or

Log in with your credentials

or    

Forgot your details?